{"id":896883,"date":"2019-12-31T13:26:46","date_gmt":"2019-12-31T20:26:46","guid":{"rendered":"https:\/\/www.myconstructionexpert.com\/blog\/?p=896883"},"modified":"2019-12-31T13:26:53","modified_gmt":"2019-12-31T20:26:53","slug":"once-again-contract-terms-matter","status":"publish","type":"post","link":"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/","title":{"rendered":"Once Again: Contract Terms Matter"},"content":{"rendered":"\n

Christopher G. Hill | Construction Law Musings<\/a><\/p>\n\n\n\n

I know, you\u2019ve heard this over and over again here at\u00a0Construction Law Musings: courts in Virginia will\u00a0interpret a contract strictly<\/a>\u00a0and in a manner that gives meaning to its unambiguous terms<\/a>.<\/p>\n\n\n\n

A recent case out of the Eastern District of Virginia federal court,\u00a0White Oak Power Constructors v. Mitsubishi Hitachi Power Systems, reinforces this point.\u00a0 The basic facts of the case relevant to this discussion and the Court\u2019s opinion are these.\u00a0 Old Dominion Electric Cooperative (ODEC) hired White Oak Power Constructors (White Oak) to build a natural gas power plant.\u00a0 The contract between ODEC and White Oak provided for liquidated damages for delay and also contained a risk of loss provision making ODEC responsible for certain losses or damages due to property damage at the plant.\u00a0 I highly recommend that you read the facts of the case in full to get the details of the terms of these clauses.<\/p>\n\n\n\n

Needless to say (or this case wouldn\u2019t be the subject of a construction law blog), the project ran past completion date and liquidated damages were assessed to the tune of more than $50,000,000.00.  The delay was alleged to have been caused in substantial part by property damage due to weather, fire, and ice among other causes.<\/p>\n\n\n\n

In a creative piece of lawyering, Whlte Oak argued that because the delay was due to property damage, ODEC, and not White Oak, was responsible for any delay related costs (including liquidated damages) that were linked to the property damage.  Of course ODEC did not agree.<\/p>\n\n\n\n

After going through several cannons of Virginia contract interpretation, the Court determined among other things, that to have a liquidated damages provision in a contract that would then essentially be cancelled out by a risk of loss provision would be absurd. The Court also determined that the context and entirety of the contract rendered White Oak\u2019s argument untenable, stating:<\/p>\n\n\n\n

There is only one reasonable interpretation of the risk of loss provision: that Old Dominion\u2019s liability for property damage under the risk of loss provision does not include corresponding \u201cdelay-related losses, damages, and costs.\u201d Accordingly, the provision is unambiguous, and the court may enforce its interpretation as a matter of law. Because the language of the contract is unambiguous, the court does not need to consider extrinsic evidence.<\/p><\/blockquote>\n\n\n\n

In sum, the Court looked at the contract and enforced its unambiguous provisions despite some wonderfully creative arguments from White Oak.\u00a0 This case further cements the maxim that Virginia law will not seek to go beyond the contract where the terms are unambiguous.\u00a0 Further, you should always seek counsel from an\u00a0experienced construction attorney\u00a0when analyzing the terms of a construction contract, hopefully prior to entering into that contract.<\/p>\n","protected":false},"excerpt":{"rendered":"

Christopher G. Hill | Construction Law Musings I know, you\u2019ve heard this over and over again here at\u00a0Construction Law Musings: courts in Virginia will\u00a0interpret a contract strictly\u00a0and in a manner that gives meaning to its unambiguous terms. A recent case out of the Eastern District of Virginia federal court,\u00a0White Oak Power Constructors v. Mitsubishi Hitachi… Continue reading Once Again: Contract Terms Matter<\/span><\/a><\/p>\n","protected":false},"author":1,"featured_media":0,"comment_status":"open","ping_status":"open","sticky":false,"template":"","format":"standard","meta":{"jetpack_post_was_ever_published":false,"_jetpack_newsletter_access":"","_jetpack_dont_email_post_to_subs":false,"_jetpack_newsletter_tier_id":0,"_jetpack_memberships_contains_paywalled_content":false,"_jetpack_memberships_contains_paid_content":false,"footnotes":"","jetpack_publicize_message":"","jetpack_publicize_feature_enabled":true,"jetpack_social_post_already_shared":true,"jetpack_social_options":{"image_generator_settings":{"template":"highway","enabled":false},"version":2}},"categories":[9],"tags":[9895,224,357],"class_list":["post-896883","post","type-post","status-publish","format-standard","hentry","category-construction-contracts","tag-advise-consult","tag-construction-contract","tag-virginia","entry"],"jetpack_publicize_connections":[],"yoast_head":"\nOnce Again: Contract Terms Matter - Advise & Consult, Inc.<\/title>\n<meta name=\"description\" content=\"I know, you\u2019ve heard this: courts in Virginia will interpret a construction contract strictly and in a manner that gives meaning to its unambiguous terms\" \/>\n<meta name=\"robots\" content=\"index, follow, max-snippet:-1, max-image-preview:large, max-video-preview:-1\" \/>\n<link rel=\"canonical\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/\" \/>\n<meta property=\"og:locale\" content=\"en_US\" \/>\n<meta property=\"og:type\" content=\"article\" \/>\n<meta property=\"og:title\" content=\"Once Again: Contract Terms Matter - Advise & Consult, Inc.\" \/>\n<meta property=\"og:description\" content=\"I know, you\u2019ve heard this: courts in Virginia will interpret a construction contract strictly and in a manner that gives meaning to its unambiguous terms\" \/>\n<meta property=\"og:url\" content=\"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/\" \/>\n<meta property=\"og:site_name\" content=\"Advise & Consult, Inc.\" \/>\n<meta property=\"article:publisher\" content=\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\" \/>\n<meta property=\"article:published_time\" content=\"2019-12-31T20:26:46+00:00\" \/>\n<meta property=\"article:modified_time\" content=\"2019-12-31T20:26:53+00:00\" \/>\n<meta name=\"author\" content=\"admin\" \/>\n<meta name=\"twitter:card\" content=\"summary_large_image\" \/>\n<meta name=\"twitter:creator\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:site\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:label1\" content=\"Written by\" \/>\n\t<meta name=\"twitter:data1\" content=\"admin\" \/>\n\t<meta name=\"twitter:label2\" content=\"Est. reading time\" \/>\n\t<meta name=\"twitter:data2\" content=\"2 minutes\" \/>\n<script type=\"application\/ld+json\" class=\"yoast-schema-graph\">{\"@context\":\"https:\/\/schema.org\",\"@graph\":[{\"@type\":\"Article\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/#article\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/\"},\"author\":{\"name\":\"admin\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\"},\"headline\":\"Once Again: Contract Terms Matter\",\"datePublished\":\"2019-12-31T20:26:46+00:00\",\"dateModified\":\"2019-12-31T20:26:53+00:00\",\"mainEntityOfPage\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/\"},\"wordCount\":466,\"commentCount\":0,\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"keywords\":[\"Advise & Consult\",\"Construction Contract\",\"Virginia\"],\"articleSection\":[\"Construction Contracts\"],\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"CommentAction\",\"name\":\"Comment\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/#respond\"]}]},{\"@type\":\"WebPage\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/\",\"name\":\"Once Again: Contract Terms Matter - Advise & Consult, Inc.\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\"},\"datePublished\":\"2019-12-31T20:26:46+00:00\",\"dateModified\":\"2019-12-31T20:26:53+00:00\",\"description\":\"I know, you\u2019ve heard this: courts in Virginia will interpret a construction contract strictly and in a manner that gives meaning to its unambiguous terms\",\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"ReadAction\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/\"]}]},{\"@type\":\"WebSite\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"name\":\"Advise & Consult, Inc.\",\"description\":\"Construction Expert Witnesses\",\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"potentialAction\":[{\"@type\":\"SearchAction\",\"target\":{\"@type\":\"EntryPoint\",\"urlTemplate\":\"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}\"},\"query-input\":{\"@type\":\"PropertyValueSpecification\",\"valueRequired\":true,\"valueName\":\"search_term_string\"}}],\"inLanguage\":\"en-US\"},{\"@type\":\"Organization\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\",\"name\":\"Advise & Consult\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"logo\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"contentUrl\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"width\":162,\"height\":75,\"caption\":\"Advise & Consult\"},\"image\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\"},\"sameAs\":[\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\",\"https:\/\/x.com\/adviseconsult\",\"https:\/\/www.linkedin.com\/company-beta\/204526\/\",\"https:\/\/www.youtube.com\/user\/MrConstructionExpert\"]},{\"@type\":\"Person\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\",\"name\":\"admin\",\"image\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/\",\"url\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"contentUrl\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"caption\":\"admin\"},\"sameAs\":[\"http:\/\/www.expertwitnessinconstruction.com\"]}]}<\/script>\n<!-- \/ Yoast SEO plugin. -->","yoast_head_json":{"title":"Once Again: Contract Terms Matter - Advise & Consult, Inc.","description":"I know, you\u2019ve heard this: courts in Virginia will interpret a construction contract strictly and in a manner that gives meaning to its unambiguous terms","robots":{"index":"index","follow":"follow","max-snippet":"max-snippet:-1","max-image-preview":"max-image-preview:large","max-video-preview":"max-video-preview:-1"},"canonical":"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/","og_locale":"en_US","og_type":"article","og_title":"Once Again: Contract Terms Matter - Advise & Consult, Inc.","og_description":"I know, you\u2019ve heard this: courts in Virginia will interpret a construction contract strictly and in a manner that gives meaning to its unambiguous terms","og_url":"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/","og_site_name":"Advise & Consult, Inc.","article_publisher":"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","article_published_time":"2019-12-31T20:26:46+00:00","article_modified_time":"2019-12-31T20:26:53+00:00","author":"admin","twitter_card":"summary_large_image","twitter_creator":"@adviseconsult","twitter_site":"@adviseconsult","twitter_misc":{"Written by":"admin","Est. reading time":"2 minutes"},"schema":{"@context":"https:\/\/schema.org","@graph":[{"@type":"Article","@id":"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/#article","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/"},"author":{"name":"admin","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7"},"headline":"Once Again: Contract Terms Matter","datePublished":"2019-12-31T20:26:46+00:00","dateModified":"2019-12-31T20:26:53+00:00","mainEntityOfPage":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/"},"wordCount":466,"commentCount":0,"publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"keywords":["Advise & Consult","Construction Contract","Virginia"],"articleSection":["Construction Contracts"],"inLanguage":"en-US","potentialAction":[{"@type":"CommentAction","name":"Comment","target":["https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/#respond"]}]},{"@type":"WebPage","@id":"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/","name":"Once Again: Contract Terms Matter - Advise & Consult, Inc.","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website"},"datePublished":"2019-12-31T20:26:46+00:00","dateModified":"2019-12-31T20:26:53+00:00","description":"I know, you\u2019ve heard this: courts in Virginia will interpret a construction contract strictly and in a manner that gives meaning to its unambiguous terms","inLanguage":"en-US","potentialAction":[{"@type":"ReadAction","target":["https:\/\/www.myconstructionexpert.com\/blog\/once-again-contract-terms-matter\/"]}]},{"@type":"WebSite","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website","url":"https:\/\/www.myconstructionexpert.com\/blog\/","name":"Advise & Consult, Inc.","description":"Construction Expert Witnesses","publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"potentialAction":[{"@type":"SearchAction","target":{"@type":"EntryPoint","urlTemplate":"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}"},"query-input":{"@type":"PropertyValueSpecification","valueRequired":true,"valueName":"search_term_string"}}],"inLanguage":"en-US"},{"@type":"Organization","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization","name":"Advise & Consult","url":"https:\/\/www.myconstructionexpert.com\/blog\/","logo":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","contentUrl":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","width":162,"height":75,"caption":"Advise & Consult"},"image":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/"},"sameAs":["https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","https:\/\/x.com\/adviseconsult","https:\/\/www.linkedin.com\/company-beta\/204526\/","https:\/\/www.youtube.com\/user\/MrConstructionExpert"]},{"@type":"Person","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7","name":"admin","image":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/","url":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","contentUrl":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","caption":"admin"},"sameAs":["http:\/\/www.expertwitnessinconstruction.com"]}]}},"jetpack_featured_media_url":"","jetpack_sharing_enabled":true,"jetpack_shortlink":"https:\/\/wp.me\/p2ztG6-3LjR","jetpack_likes_enabled":true,"_links":{"self":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/896883","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/users\/1"}],"replies":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/comments?post=896883"}],"version-history":[{"count":1,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/896883\/revisions"}],"predecessor-version":[{"id":896884,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/896883\/revisions\/896884"}],"wp:attachment":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/media?parent=896883"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/categories?post=896883"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/tags?post=896883"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}