{"id":897718,"date":"2020-07-16T11:38:50","date_gmt":"2020-07-16T17:38:50","guid":{"rendered":"https:\/\/www.myconstructionexpert.com\/blog\/?p=897718"},"modified":"2020-07-16T11:38:54","modified_gmt":"2020-07-16T17:38:54","slug":"differing-site-condition-contract-interpretation","status":"publish","type":"post","link":"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/","title":{"rendered":"Don\u2019t Be Unreasonable: Equitable Adjustment Conditioned on Government Contractor\u2019s Proof of Reasonable Interpretation of Contract"},"content":{"rendered":"\n<p>Douglas L. Patin, Aron C. Beezley &amp; Amandeep S. Kahlon | <a rel=\"noreferrer noopener\" href=\"https:\/\/www.buildsmartbradley.com\/2020\/07\/dont-be-unreasonable-equitable-adjustment-conditioned-on-government-contractors-proof-of-reasonable-interpretation-of-contract\/?utm_source=Bradley+Arant+Boult+Cummings+LLP+-+BuildSmart&amp;utm_campaign=a9086d7ed1-RSS_EMAIL_CAMPAIGN&amp;utm_medium=email&amp;utm_term=0_b504caf31b-a9086d7ed1-78863422\" target=\"_blank\">Buildsmart<\/a><\/p>\n\n\n\n<p>The U.S. Court of Appeals for the Federal Circuit, in\u00a0<em>U.S. Army Corps of Engineers v. John C. Grimberg Co., Inc.<\/em>, recently reversed an Armed Services Board of Contract Appeals (ASBCA) decision that a federal contractor was entitled to an equitable adjustment on a <a href=\"https:\/\/www.myconstructionexpert.com\/blog\/common-issues-differing-site-conditions-clause\/\" target=\"_blank\" rel=\"noreferrer noopener\">differing site conditions<\/a> claim. The Federal Circuit held that the contractor, in developing its proposal, did not demonstrate that its interpretation of government subsurface data was reasonable \u2014 a condition precedent to entitlement for an equitable adjustment. Even though the ASBCA agreed that the subsurface conditions actually encountered far exceeded what a reasonable interpretation of the subsurface data would have allowed for, as discussed below, the Federal Circuit determined such a finding could not cure the contractor\u2019s initial deficient interpretation or justify an equitable adjustment.<\/p>\n\n\n\n<h2 class=\"wp-block-heading\"><strong>The Facts<\/strong><\/h2>\n\n\n\n<p>In 2009, the U.S. Army Corps of Engineers issued a solicitation for the design and construction of a biolab facility on an existing biodefense campus in Maryland. The solicitation called for the use of rock socket, drilled foundations. The bid documents included a geotechnical report that disclosed 46 test borings, only two of which were located within the footprint of the new biolab building. Those two test borings showed clean rock in the subsurface with no intervening incompetent rock. However, the geotechnical report advised contractors not to assume that rock on the site would be free of voids given information available from the other borings taken elsewhere on the existing campus site.<\/p>\n\n\n\n<p>The contractor, John C. Grimberg Co., Inc., relied on the two test borings within the building footprint to bid the project and assumed that excavation of incompetent rock would not be required. Once work began, however, the contractor encountered substantial incompetent rock and notified the Corps that, in its view, the additional rock drilling constituted a differing site condition. At the end of the project, the contractor sought an equitable adjustment for an additional 683 feet of drilling through incompetent rock, which the Corps denied. The contractor appealed this decision to the ASBCA.<\/p>\n\n\n\n<p>The ASBCA concluded the contractor did encounter a differing site condition based on the quantities of rock greatly exceeding the quantity reasonably foreseeable. Specifically, the ASBCA found that, although it was unreasonable for the contractor to rely on just the two borings within the building footprint to quote the project, the contractor\u2019s approach was less unreasonable than the Corps\u2019 suggestion that the contractor should have relied on data from borings elsewhere on the campus site. Some of these other borings were 300 to 500 feet away from the biolab building footprint.<\/p>\n\n\n\n<p>The ASBCA also surmised that, even accounting for the other boring results, the actual quantity of incompetent rock encountered far exceeded what was reasonably foreseeable. After evaluating the difference between the amount of drilling the contractor should have reasonably anticipated versus the actual amount encountered, the ASBCA awarded the contractor direct costs and delay damages for excess drilling through an additional 563 feet of incompetent rock.<\/p>\n\n\n\n<p>The Corps appealed to the Federal Circuit, arguing that the contractor\u2019s failure to demonstrate a reasonable interpretation of and reliance on the contract documents, including the geotechnical report, foreclosed any entitlement to an equitable adjustment of the contract price. The Federal Circuit agreed with the Corps and reversed the ASBCA\u2019s decision. The Federal Circuit relied on past precedent holding that \u201cto receive an equitable adjustment to the contract price, a contractor must prove that it reasonably relied on its interpretation of the contract.\u201d Because the ASBCA concluded that the contractor\u2019s interpretation of the contract documents was unreasonable, the Corps\u2019 higher relative degree of unreasonableness could not be used as a basis for granting the contractor an equitable adjustment. Per the Federal Circuit, \u201cthe focus of [its] inquiry must be on the reasonableness of the contractor,\u201d which \u201cserves the purpose of incentivizing contractors to carefully and reasonably interpret contract documents.\u201d<\/p>\n\n\n\n<h2 class=\"wp-block-heading\"><strong>Lessons from This Decision<\/strong><\/h2>\n\n\n\n<p>The result in&nbsp;<em>John C. Grimberg<\/em>&nbsp;is a harsh one for the contractor, given the acknowledgement that the contractor encountered conditions that far exceeded what even a reasonable interpretation of the contract documents would have disclosed. Nonetheless, the Federal Circuit\u2019s decision in this case serves as an important reminder to federal contractors that, while their interpretation of contract documents need not be the&nbsp;<em>only<\/em>&nbsp;reasonable one, their interpretation of and reliance on contract documents must at least be&nbsp;<em>a<\/em>&nbsp;reasonable one to recover under a differing site conditions claim.<\/p>\n","protected":false},"excerpt":{"rendered":"<p>Douglas L. Patin, Aron C. Beezley &amp; Amandeep S. Kahlon | Buildsmart The U.S. Court of Appeals for the Federal Circuit, in\u00a0U.S. Army Corps of Engineers v. John C. Grimberg Co., Inc., recently reversed an Armed Services Board of Contract Appeals (ASBCA) decision that a federal contractor was entitled to an equitable adjustment on a&hellip; <a class=\"more-link\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/\">Continue reading <span class=\"screen-reader-text\">Don\u2019t Be Unreasonable: Equitable Adjustment Conditioned on Government Contractor\u2019s Proof of Reasonable Interpretation of Contract<\/span><\/a><\/p>\n","protected":false},"author":1,"featured_media":0,"comment_status":"open","ping_status":"open","sticky":false,"template":"","format":"standard","meta":{"jetpack_post_was_ever_published":false,"_jetpack_newsletter_access":"","_jetpack_dont_email_post_to_subs":false,"_jetpack_newsletter_tier_id":0,"_jetpack_memberships_contains_paywalled_content":false,"_jetpack_memberships_contains_paid_content":false,"footnotes":"","jetpack_publicize_message":"","jetpack_publicize_feature_enabled":true,"jetpack_social_post_already_shared":true,"jetpack_social_options":{"image_generator_settings":{"template":"highway","enabled":false},"version":2}},"categories":[9],"tags":[9895,224,8994,11229],"class_list":["post-897718","post","type-post","status-publish","format-standard","hentry","category-construction-contracts","tag-advise-consult","tag-construction-contract","tag-differing-site-conditions","tag-reasonable-interpretation","entry"],"jetpack_publicize_connections":[],"yoast_head":"<!-- This site is optimized with the Yoast SEO plugin v25.0 - https:\/\/yoast.com\/wordpress\/plugins\/seo\/ -->\n<title>Don\u2019t Be Unreasonable: Equitable Adjustment Conditioned on Government Contractor\u2019s Proof of Reasonable Interpretation of Contract - Advise &amp; Consult, Inc.<\/title>\n<meta name=\"description\" content=\"the contractor did not demonstrate that its interpretation of government subsurface data was reasonable \u2014 a condition for an equitable adjustment\" \/>\n<meta name=\"robots\" content=\"index, follow, max-snippet:-1, max-image-preview:large, max-video-preview:-1\" \/>\n<link rel=\"canonical\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/\" \/>\n<meta property=\"og:locale\" content=\"en_US\" \/>\n<meta property=\"og:type\" content=\"article\" \/>\n<meta property=\"og:title\" content=\"Don\u2019t Be Unreasonable: Equitable Adjustment Conditioned on Government Contractor\u2019s Proof of Reasonable Interpretation of Contract - Advise &amp; Consult, Inc.\" \/>\n<meta property=\"og:description\" content=\"the contractor did not demonstrate that its interpretation of government subsurface data was reasonable \u2014 a condition for an equitable adjustment\" \/>\n<meta property=\"og:url\" content=\"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/\" \/>\n<meta property=\"og:site_name\" content=\"Advise &amp; Consult, Inc.\" \/>\n<meta property=\"article:publisher\" content=\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\" \/>\n<meta property=\"article:published_time\" content=\"2020-07-16T17:38:50+00:00\" \/>\n<meta property=\"article:modified_time\" content=\"2020-07-16T17:38:54+00:00\" \/>\n<meta name=\"author\" content=\"admin\" \/>\n<meta name=\"twitter:card\" content=\"summary_large_image\" \/>\n<meta name=\"twitter:creator\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:site\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:label1\" content=\"Written by\" \/>\n\t<meta name=\"twitter:data1\" content=\"admin\" \/>\n\t<meta name=\"twitter:label2\" content=\"Est. reading time\" \/>\n\t<meta name=\"twitter:data2\" content=\"4 minutes\" \/>\n<script type=\"application\/ld+json\" class=\"yoast-schema-graph\">{\"@context\":\"https:\/\/schema.org\",\"@graph\":[{\"@type\":\"Article\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/#article\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/\"},\"author\":{\"name\":\"admin\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\"},\"headline\":\"Don\u2019t Be Unreasonable: Equitable Adjustment Conditioned on Government Contractor\u2019s Proof of Reasonable Interpretation of Contract\",\"datePublished\":\"2020-07-16T17:38:50+00:00\",\"dateModified\":\"2020-07-16T17:38:54+00:00\",\"mainEntityOfPage\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/\"},\"wordCount\":771,\"commentCount\":0,\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"keywords\":[\"Advise &amp; Consult\",\"Construction Contract\",\"Differing Site Conditions\",\"Reasonable Interpretation\"],\"articleSection\":[\"Construction Contracts\"],\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"CommentAction\",\"name\":\"Comment\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/#respond\"]}]},{\"@type\":\"WebPage\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/\",\"name\":\"Don\u2019t Be Unreasonable: Equitable Adjustment Conditioned on Government Contractor\u2019s Proof of Reasonable Interpretation of Contract - Advise &amp; Consult, Inc.\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\"},\"datePublished\":\"2020-07-16T17:38:50+00:00\",\"dateModified\":\"2020-07-16T17:38:54+00:00\",\"description\":\"the contractor did not demonstrate that its interpretation of government subsurface data was reasonable \u2014 a condition for an equitable adjustment\",\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"ReadAction\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/\"]}]},{\"@type\":\"WebSite\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"name\":\"Advise &amp; Consult, Inc.\",\"description\":\"Construction Expert Witnesses\",\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"potentialAction\":[{\"@type\":\"SearchAction\",\"target\":{\"@type\":\"EntryPoint\",\"urlTemplate\":\"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}\"},\"query-input\":{\"@type\":\"PropertyValueSpecification\",\"valueRequired\":true,\"valueName\":\"search_term_string\"}}],\"inLanguage\":\"en-US\"},{\"@type\":\"Organization\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\",\"name\":\"Advise & Consult\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"logo\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"contentUrl\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"width\":162,\"height\":75,\"caption\":\"Advise & Consult\"},\"image\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\"},\"sameAs\":[\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\",\"https:\/\/x.com\/adviseconsult\",\"https:\/\/www.linkedin.com\/company-beta\/204526\/\",\"https:\/\/www.youtube.com\/user\/MrConstructionExpert\"]},{\"@type\":\"Person\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\",\"name\":\"admin\",\"image\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/\",\"url\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"contentUrl\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"caption\":\"admin\"},\"sameAs\":[\"http:\/\/www.expertwitnessinconstruction.com\"]}]}<\/script>\n<!-- \/ Yoast SEO plugin. -->","yoast_head_json":{"title":"Don\u2019t Be Unreasonable: Equitable Adjustment Conditioned on Government Contractor\u2019s Proof of Reasonable Interpretation of Contract - Advise &amp; Consult, Inc.","description":"the contractor did not demonstrate that its interpretation of government subsurface data was reasonable \u2014 a condition for an equitable adjustment","robots":{"index":"index","follow":"follow","max-snippet":"max-snippet:-1","max-image-preview":"max-image-preview:large","max-video-preview":"max-video-preview:-1"},"canonical":"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/","og_locale":"en_US","og_type":"article","og_title":"Don\u2019t Be Unreasonable: Equitable Adjustment Conditioned on Government Contractor\u2019s Proof of Reasonable Interpretation of Contract - Advise &amp; Consult, Inc.","og_description":"the contractor did not demonstrate that its interpretation of government subsurface data was reasonable \u2014 a condition for an equitable adjustment","og_url":"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/","og_site_name":"Advise &amp; Consult, Inc.","article_publisher":"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","article_published_time":"2020-07-16T17:38:50+00:00","article_modified_time":"2020-07-16T17:38:54+00:00","author":"admin","twitter_card":"summary_large_image","twitter_creator":"@adviseconsult","twitter_site":"@adviseconsult","twitter_misc":{"Written by":"admin","Est. reading time":"4 minutes"},"schema":{"@context":"https:\/\/schema.org","@graph":[{"@type":"Article","@id":"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/#article","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/"},"author":{"name":"admin","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7"},"headline":"Don\u2019t Be Unreasonable: Equitable Adjustment Conditioned on Government Contractor\u2019s Proof of Reasonable Interpretation of Contract","datePublished":"2020-07-16T17:38:50+00:00","dateModified":"2020-07-16T17:38:54+00:00","mainEntityOfPage":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/"},"wordCount":771,"commentCount":0,"publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"keywords":["Advise &amp; Consult","Construction Contract","Differing Site Conditions","Reasonable Interpretation"],"articleSection":["Construction Contracts"],"inLanguage":"en-US","potentialAction":[{"@type":"CommentAction","name":"Comment","target":["https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/#respond"]}]},{"@type":"WebPage","@id":"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/","name":"Don\u2019t Be Unreasonable: Equitable Adjustment Conditioned on Government Contractor\u2019s Proof of Reasonable Interpretation of Contract - Advise &amp; Consult, Inc.","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website"},"datePublished":"2020-07-16T17:38:50+00:00","dateModified":"2020-07-16T17:38:54+00:00","description":"the contractor did not demonstrate that its interpretation of government subsurface data was reasonable \u2014 a condition for an equitable adjustment","inLanguage":"en-US","potentialAction":[{"@type":"ReadAction","target":["https:\/\/www.myconstructionexpert.com\/blog\/differing-site-condition-contract-interpretation\/"]}]},{"@type":"WebSite","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website","url":"https:\/\/www.myconstructionexpert.com\/blog\/","name":"Advise &amp; Consult, Inc.","description":"Construction Expert Witnesses","publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"potentialAction":[{"@type":"SearchAction","target":{"@type":"EntryPoint","urlTemplate":"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}"},"query-input":{"@type":"PropertyValueSpecification","valueRequired":true,"valueName":"search_term_string"}}],"inLanguage":"en-US"},{"@type":"Organization","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization","name":"Advise & Consult","url":"https:\/\/www.myconstructionexpert.com\/blog\/","logo":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","contentUrl":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","width":162,"height":75,"caption":"Advise & Consult"},"image":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/"},"sameAs":["https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","https:\/\/x.com\/adviseconsult","https:\/\/www.linkedin.com\/company-beta\/204526\/","https:\/\/www.youtube.com\/user\/MrConstructionExpert"]},{"@type":"Person","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7","name":"admin","image":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/","url":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","contentUrl":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","caption":"admin"},"sameAs":["http:\/\/www.expertwitnessinconstruction.com"]}]}},"jetpack_featured_media_url":"","jetpack_sharing_enabled":true,"jetpack_shortlink":"https:\/\/wp.me\/p2ztG6-3Lxk","jetpack_likes_enabled":true,"_links":{"self":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/897718","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/users\/1"}],"replies":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/comments?post=897718"}],"version-history":[{"count":1,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/897718\/revisions"}],"predecessor-version":[{"id":897719,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/897718\/revisions\/897719"}],"wp:attachment":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/media?parent=897718"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/categories?post=897718"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/tags?post=897718"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}