{"id":897942,"date":"2020-09-10T10:43:18","date_gmt":"2020-09-10T16:43:18","guid":{"rendered":"https:\/\/www.myconstructionexpert.com\/blog\/?p=897942"},"modified":"2020-09-10T10:43:39","modified_gmt":"2020-09-10T16:43:39","slug":"liquidated-damages-applicability","status":"publish","type":"post","link":"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/","title":{"rendered":"Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can\u2019t Look Back Again)"},"content":{"rendered":"\n<p>Christopher G. Hill | <a rel=\"noreferrer noopener\" href=\"https:\/\/constructionlawva.com\/reasonableness-of-liquidated-damages-determined-at-time-of-contract-or-you-cant-look-back-again\/?utm_source=feedburner&amp;utm_medium=email&amp;utm_campaign=Feed%3A+ConstructionLawMusings-RichmondVa+%28Construction+Law+Musings-+Richmond%2C+VA%29\" target=\"_blank\">Construction Law Musings<\/a><\/p>\n\n\n\n<p>I\u2019ve discussed the continuing litigation between\u00a0<em>White Oak Power Constructors v. Mitsubishi Hitachi Power Systems Americas, Inc.<\/em>\u00a0previously here at\u00a0Construction Law Musings\u00a0because the case was another reminder that\u00a0your <a href=\"https:\/\/www.myconstructionexpert.com\/blog\/construction-contract-interpretation-critical\/\" target=\"_blank\" rel=\"noreferrer noopener\">construction contract terms matter<\/a>\u00a0and will be interpreted strictly here in the Commonwealth of Virginia.\u00a0 The prior opinion in this case from the Eastern District of Virginia court the Court considered the\u00a0<em>applicability\u00a0<\/em>of a <a href=\"https:\/\/www.myconstructionexpert.com\/blog\/think-that-liquidated-damages-provision-you-just-agreed-to-is-unenforceable-think-again\/\" target=\"_blank\" rel=\"noreferrer noopener\">liquidated damages provision<\/a>.\u00a0 In the\u00a0<a href=\"https:\/\/constructionlawva.com\/wp-content\/uploads\/2020\/08\/White-Oak-Power-Constructors-v.-Mitsubishi-Hitachi-Power-Systems-Americas-Inc.-2.pdf\" target=\"_blank\" rel=\"noreferrer noopener\">latest opinion from the Court<\/a>\u00a0(PDF) the Court looked at when and how any liquidated damages would be calculated.\u00a0 In its June 22, 2020 opinion, the Court put the issue as follows:<\/p>\n\n\n\n<blockquote class=\"wp-block-quote is-layout-flow wp-block-quote-is-layout-flow\"><p>White Oak\u2019s motion for partial summary judgment presents a narrow issue: whether courts may consider the damages actually sustained by a party as a result of a contract breach when deciding if liquidated damages required by a contract \u201cgrossly exceed\u201d a party\u2019s actual damages.<\/p><\/blockquote>\n\n\n\n<p>Mitsubishi argued that White Oak could not enforce the liquidated damages provisions of the contract (all of which are laid out in the opinion linked above) because the liquidated damages were not reasonable and \u201cgrossly exceeded\u201d the actual damages incurred by White Oak because of project delays allegedly caused by Mitsubishi.&nbsp; Mitsubishi argued that the Court must look retroactively at the actual damages incurred when determining whether the liquidated damages constituted a penalty.&nbsp; White Oak argued that the Court should look proactively at what the parties thought damages could be at the time of contracting.&nbsp; After a thorough review of Virginia law, the Court agreed with White Oak and stated:<\/p>\n\n\n\n<blockquote class=\"wp-block-quote is-layout-flow wp-block-quote-is-layout-flow\"><p>[c]ourts applying Virginia law must consider the actual damages contemplated at the time of contract when determining the reasonableness of a liquidated damages provision. Moreover, the fact that courts must focus on the intent of the parties based on the circumstances at the time of contract formation further supports applying the prospective approach. Accordingly, Mitsubishi may not challenge the liquidated damages provision based on the damages White Oak suffered after the alleged delays occurred.<\/p><\/blockquote>\n\n\n\n<p>In short, when drafting or reviewing liquidated damages provisions for your construction contracts with the assistance of an\u00a0experienced Virginia construction lawyer, be sure to have them be \u201cindexed\u201d to the prospective damages the parties reasonably consider to be possible when the contract is made.\u00a0 You are not likely to win an argument after the fact-based upon the actual damages incurred.<\/p>\n\n\n\n<p>As always, I recommend that you read the entire opinion for yourself and draw your own conclusions.&nbsp; Also, please let me know with a comment if you have any thoughts on my analysis.<\/p>\n","protected":false},"excerpt":{"rendered":"<p>Christopher G. Hill | Construction Law Musings I\u2019ve discussed the continuing litigation between\u00a0White Oak Power Constructors v. Mitsubishi Hitachi Power Systems Americas, Inc.\u00a0previously here at\u00a0Construction Law Musings\u00a0because the case was another reminder that\u00a0your construction contract terms matter\u00a0and will be interpreted strictly here in the Commonwealth of Virginia.\u00a0 The prior opinion in this case from the&hellip; <a class=\"more-link\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/\">Continue reading <span class=\"screen-reader-text\">Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can\u2019t Look Back Again)<\/span><\/a><\/p>\n","protected":false},"author":1,"featured_media":0,"comment_status":"open","ping_status":"open","sticky":false,"template":"","format":"standard","meta":{"jetpack_post_was_ever_published":false,"_jetpack_newsletter_access":"","_jetpack_dont_email_post_to_subs":false,"_jetpack_newsletter_tier_id":0,"_jetpack_memberships_contains_paywalled_content":false,"_jetpack_memberships_contains_paid_content":false,"footnotes":"","jetpack_publicize_message":"","jetpack_publicize_feature_enabled":true,"jetpack_social_post_already_shared":true,"jetpack_social_options":{"image_generator_settings":{"template":"highway","enabled":false},"version":2}},"categories":[9],"tags":[9895,10891,9112,357],"class_list":["post-897942","post","type-post","status-publish","format-standard","hentry","category-construction-contracts","tag-advise-consult","tag-construction-contract-provisions","tag-liquidated-damages","tag-virginia","entry"],"jetpack_publicize_connections":[],"yoast_head":"<!-- This site is optimized with the Yoast SEO plugin v25.0 - https:\/\/yoast.com\/wordpress\/plugins\/seo\/ -->\n<title>Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can\u2019t Look Back Again) - Advise &amp; Consult, Inc.<\/title>\n<meta name=\"description\" content=\"opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision\" \/>\n<meta name=\"robots\" content=\"index, follow, max-snippet:-1, max-image-preview:large, max-video-preview:-1\" \/>\n<link rel=\"canonical\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/\" \/>\n<meta property=\"og:locale\" content=\"en_US\" \/>\n<meta property=\"og:type\" content=\"article\" \/>\n<meta property=\"og:title\" content=\"Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can\u2019t Look Back Again) - Advise &amp; Consult, Inc.\" \/>\n<meta property=\"og:description\" content=\"opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision\" \/>\n<meta property=\"og:url\" content=\"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/\" \/>\n<meta property=\"og:site_name\" content=\"Advise &amp; Consult, Inc.\" \/>\n<meta property=\"article:publisher\" content=\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\" \/>\n<meta property=\"article:published_time\" content=\"2020-09-10T16:43:18+00:00\" \/>\n<meta property=\"article:modified_time\" content=\"2020-09-10T16:43:39+00:00\" \/>\n<meta name=\"author\" content=\"admin\" \/>\n<meta name=\"twitter:card\" content=\"summary_large_image\" \/>\n<meta name=\"twitter:creator\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:site\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:label1\" content=\"Written by\" \/>\n\t<meta name=\"twitter:data1\" content=\"admin\" \/>\n\t<meta name=\"twitter:label2\" content=\"Est. reading time\" \/>\n\t<meta name=\"twitter:data2\" content=\"2 minutes\" \/>\n<script type=\"application\/ld+json\" class=\"yoast-schema-graph\">{\"@context\":\"https:\/\/schema.org\",\"@graph\":[{\"@type\":\"Article\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/#article\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/\"},\"author\":{\"name\":\"admin\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\"},\"headline\":\"Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can\u2019t Look Back Again)\",\"datePublished\":\"2020-09-10T16:43:18+00:00\",\"dateModified\":\"2020-09-10T16:43:39+00:00\",\"mainEntityOfPage\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/\"},\"wordCount\":453,\"commentCount\":0,\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"keywords\":[\"Advise &amp; Consult\",\"Construction Contract Provisions\",\"Liquidated Damages\",\"Virginia\"],\"articleSection\":[\"Construction Contracts\"],\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"CommentAction\",\"name\":\"Comment\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/#respond\"]}]},{\"@type\":\"WebPage\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/\",\"name\":\"Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can\u2019t Look Back Again) - Advise &amp; Consult, Inc.\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\"},\"datePublished\":\"2020-09-10T16:43:18+00:00\",\"dateModified\":\"2020-09-10T16:43:39+00:00\",\"description\":\"opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision\",\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"ReadAction\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/\"]}]},{\"@type\":\"WebSite\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"name\":\"Advise &amp; Consult, Inc.\",\"description\":\"Construction Expert Witnesses\",\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"potentialAction\":[{\"@type\":\"SearchAction\",\"target\":{\"@type\":\"EntryPoint\",\"urlTemplate\":\"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}\"},\"query-input\":{\"@type\":\"PropertyValueSpecification\",\"valueRequired\":true,\"valueName\":\"search_term_string\"}}],\"inLanguage\":\"en-US\"},{\"@type\":\"Organization\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\",\"name\":\"Advise & Consult\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"logo\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"contentUrl\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"width\":162,\"height\":75,\"caption\":\"Advise & Consult\"},\"image\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\"},\"sameAs\":[\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\",\"https:\/\/x.com\/adviseconsult\",\"https:\/\/www.linkedin.com\/company-beta\/204526\/\",\"https:\/\/www.youtube.com\/user\/MrConstructionExpert\"]},{\"@type\":\"Person\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\",\"name\":\"admin\",\"image\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/\",\"url\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"contentUrl\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"caption\":\"admin\"},\"sameAs\":[\"http:\/\/www.expertwitnessinconstruction.com\"]}]}<\/script>\n<!-- \/ Yoast SEO plugin. -->","yoast_head_json":{"title":"Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can\u2019t Look Back Again) - Advise &amp; Consult, Inc.","description":"opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision","robots":{"index":"index","follow":"follow","max-snippet":"max-snippet:-1","max-image-preview":"max-image-preview:large","max-video-preview":"max-video-preview:-1"},"canonical":"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/","og_locale":"en_US","og_type":"article","og_title":"Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can\u2019t Look Back Again) - Advise &amp; Consult, Inc.","og_description":"opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision","og_url":"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/","og_site_name":"Advise &amp; Consult, Inc.","article_publisher":"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","article_published_time":"2020-09-10T16:43:18+00:00","article_modified_time":"2020-09-10T16:43:39+00:00","author":"admin","twitter_card":"summary_large_image","twitter_creator":"@adviseconsult","twitter_site":"@adviseconsult","twitter_misc":{"Written by":"admin","Est. reading time":"2 minutes"},"schema":{"@context":"https:\/\/schema.org","@graph":[{"@type":"Article","@id":"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/#article","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/"},"author":{"name":"admin","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7"},"headline":"Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can\u2019t Look Back Again)","datePublished":"2020-09-10T16:43:18+00:00","dateModified":"2020-09-10T16:43:39+00:00","mainEntityOfPage":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/"},"wordCount":453,"commentCount":0,"publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"keywords":["Advise &amp; Consult","Construction Contract Provisions","Liquidated Damages","Virginia"],"articleSection":["Construction Contracts"],"inLanguage":"en-US","potentialAction":[{"@type":"CommentAction","name":"Comment","target":["https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/#respond"]}]},{"@type":"WebPage","@id":"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/","name":"Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can\u2019t Look Back Again) - Advise &amp; Consult, Inc.","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website"},"datePublished":"2020-09-10T16:43:18+00:00","dateModified":"2020-09-10T16:43:39+00:00","description":"opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision","inLanguage":"en-US","potentialAction":[{"@type":"ReadAction","target":["https:\/\/www.myconstructionexpert.com\/blog\/liquidated-damages-applicability\/"]}]},{"@type":"WebSite","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website","url":"https:\/\/www.myconstructionexpert.com\/blog\/","name":"Advise &amp; Consult, Inc.","description":"Construction Expert Witnesses","publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"potentialAction":[{"@type":"SearchAction","target":{"@type":"EntryPoint","urlTemplate":"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}"},"query-input":{"@type":"PropertyValueSpecification","valueRequired":true,"valueName":"search_term_string"}}],"inLanguage":"en-US"},{"@type":"Organization","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization","name":"Advise & Consult","url":"https:\/\/www.myconstructionexpert.com\/blog\/","logo":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","contentUrl":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","width":162,"height":75,"caption":"Advise & Consult"},"image":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/"},"sameAs":["https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","https:\/\/x.com\/adviseconsult","https:\/\/www.linkedin.com\/company-beta\/204526\/","https:\/\/www.youtube.com\/user\/MrConstructionExpert"]},{"@type":"Person","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7","name":"admin","image":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/","url":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","contentUrl":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","caption":"admin"},"sameAs":["http:\/\/www.expertwitnessinconstruction.com"]}]}},"jetpack_featured_media_url":"","jetpack_sharing_enabled":true,"jetpack_shortlink":"https:\/\/wp.me\/p2ztG6-3LAW","jetpack_likes_enabled":true,"_links":{"self":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/897942","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/users\/1"}],"replies":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/comments?post=897942"}],"version-history":[{"count":1,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/897942\/revisions"}],"predecessor-version":[{"id":897943,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/897942\/revisions\/897943"}],"wp:attachment":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/media?parent=897942"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/categories?post=897942"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/tags?post=897942"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}