{"id":899908,"date":"2022-05-04T15:12:12","date_gmt":"2022-05-04T21:12:12","guid":{"rendered":"https:\/\/www.myconstructionexpert.com\/blog\/?p=899908"},"modified":"2022-05-04T15:12:16","modified_gmt":"2022-05-04T21:12:16","slug":"delivery-of-materials-accelerated-schedule","status":"publish","type":"post","link":"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/","title":{"rendered":"The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier"},"content":{"rendered":"\n<p>Robert M. Barrack | <a href=\"https:\/\/www.grsm.com\/publications\/2022\/the-connecticut-appellate-court-decides-that-construction-contractor-was-not-obligated-to-continue-accelerated-schedule-to-mitigate-its-damages-following-late-delivery-of-materials-by-supplier\" target=\"_blank\" rel=\"noreferrer noopener nofollow\">Gordon Rees Scully Mansukhani<\/a><\/p>\n\n\n\n<p>In\u00a0<em>United Concrete Prods. v. NJR Constr., LLC<\/em>, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the <a href=\"https:\/\/www.myconstructionexpert.com\/blog\/construction-material-late-delivery\/\" target=\"_blank\" rel=\"noreferrer noopener\">late delivery of materials<\/a> on a construction project, which is a frequent problem on construction projects. In\u00a0<em>United Concrete Products<\/em>, the defendant general contractor, NJR Construction, LLC (\u201cNJR\u201d) was retained by the State of Connecticut Department of Transportation (\u201cDOT\u201d) to replace a bridge over the Hockanum River (\u201cProject\u201d).\u00a0<em>Id.<\/em>\u00a0at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic.\u00a0<em>Id.<\/em>\u00a0The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline.\u00a0<em>Id.<\/em><\/p>\n\n\n\n<p>NJR subsequently entered into a purchase order (\u201cSubcontract\u201d) with the plaintiff, United Concrete Products, Inc. (\u201cUnited\u201d), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams.&nbsp;<em>Id.<\/em>&nbsp;The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016.&nbsp;<em>Id.<\/em>&nbsp;Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages.&nbsp;<em>Id.<\/em>&nbsp;After deducting the amount of $179,500 in damages that it incurred due to United\u2019s late delivery of the beams, NJR paid United the balance of $66,074.75.&nbsp;<em>Id<\/em>.<\/p>\n\n\n\n<p>United then filed a lawsuit in the Connecticut Superior Court seeking, among other things, payment of the full amount due under the Subcontract, without the offset, a claim for violation of Connecticut\u2019s Prompt Payment Act, as well as a claim against NJR\u2019s payment bond surety under the Connecticut\u2019s Little Miller Act.<sup>1<\/sup>&nbsp;<em>Id.<\/em>&nbsp;NJR asserted affirmative defenses and a counterclaim alleging, among other things, that United breached the Subcontract by failing to meet the delivery deadline for the beams, and violated the Connecticut Unfair Trade Practices Act (\u201cCUTPA\u201d) by repeatedly misrepresenting when it would deliver the materials.&nbsp;<em>Id.<\/em><\/p>\n\n\n\n<p>One of United\u2019s defenses to NJR\u2019s breach of contract counterclaim was that NJR had failed to mitigate its damages by failing to maintain its accelerated work schedule on the Project after United\u2019s late delivery of the beams, which would have substantially reduced NJR\u2019s damages. The defense was based upon the fact that prior to the delivery of the beams on July 26, 2016, NJR had been taking a \u201cfast-track\u201d approach to the Project; i.e., working on an accelerated schedule, in order to maximize its ability to receive the incentive bonus.&nbsp;<em>Id<\/em>. at 567. However, after United\u2019s untimely delivery of the beams, and the realization that it would not receive any incentive bonus from the DOT, NJR abandoned its fast-track approach to the schedule, and proceeded at a regular pace.&nbsp;<em>Id<\/em>.<\/p>\n\n\n\n<p>The trial court ultimately rendered judgment in favor of United on its breach of contract claim, finding that because the contract was for the sale of goods, and was therefore governed by the Article 2 of Uniform Commercial Code (\u201cUCC\u201d), the fact that NJR accepted the beams despite the late delivery, NJR was liable to pay for the full amount due under the Subcontract without a setoff.&nbsp;<em>Id<\/em>. at 560. The trial court also awarded NJR the full amount of its claimed damages against United on the counterclaim for late delivery of the beams, and also for United\u2019s violation of CUTPA.&nbsp;<em>Id<\/em>. at 559. The trial court rejected United\u2019s mitigation of damages defense. On appeal, the Connecticut Appellate Court affirmed the relevant portions of the judgment below, including with respect to the mitigation of damages issue.<\/p>\n\n\n\n<p>The Appellate Court reiterated the general proposition that in the context of contracts and torts, the party receiving the damage award has a duty to make reasonable efforts to mitigate damages.&nbsp;<em>Id<\/em>. at 567. The Court further explained as follows: \u201cTo claim successfully that the plaintiff [or counterclaim plaintiff] failed to mitigate damages, the defendant [or counterclaim defendant] must show that the injured party failed to take reasonable action to lessen the damages; that the damages were in fact enhanced by such failure; and that the damages which could have been avoided can be measured with reasonable certainty. &#8230; Furthermore, [t]he duty to mitigate damages does not require a party to sacrifice a substantial right of his own in order to minimize a loss.\u201d&nbsp;<em>Id<\/em>. (quoting&nbsp;<em>Sun Val, LLC v. Commissioner of Transportation<\/em>, 330 Conn. 316, 334, 193 A.3d 1192 (2018)).<\/p>\n\n\n\n<p>Although United argued that the trial court erred by failing to offset or reduce NJR\u2019s damages based on failure to mitigate because NJR abandoned its fast-track work schedule following the late delivery of the beams, the Appellate Court disagreed. The Court agreed with NJR\u2019s position that once NJR realized that it was not going obtain the incentive bonus due to United\u2019s late delivery of the beams, the was no reason for NJR to continue with the accelerated schedule.&nbsp;<em>Id<\/em>. at 567-68. Because NJR was only obligated to make reasonable efforts to mitigate its damages, such reasonable effort only entailed working at a normal, rather than an accelerated pace.&nbsp;<em>Id<\/em>. at 568.<\/p>\n\n\n\n<p>What is interesting about this decision is that NJR had already established the fast-track schedule for the Project, but only reduced it to a normal schedule after United\u2019s late delivery of the beams, rather than maintaining the status quo. Nevertheless, the Appellate Court found once United breached the Subcontract by delivering the beams late, thus eliminating the very reason that NJR was operating on the accelerated schedule, it was no longer reasonable to expect NJR to maintain that accelerated schedule. Accordingly, under the proper circumstances, a party can defeat a failure to mitigate defense, even if its post-breach conduct arguably increased its damages.<br>__________________________________________________________________________<\/p>\n\n\n\n<p><sup>1<\/sup>\u00a0The payment bond claim and other issues discussed in the lengthy appellate decision are outside the scope of this article, which is focused on the mitigation of damages issue.<\/p>\n\n\n\n<p><\/p>\n\n\n\n<p><strong>When one of your cases is in need of a construction expert, estimates, insurance appraisal or umpire services in defect or insurance disputes &#8211; please call Advise &amp; Consult, Inc. at 888.684.8305, or email <a href=\"mailto:experts@adviseandconsult.net\" target=\"_blank\" rel=\"noreferrer noopener\">experts@adviseandconsult.net<\/a>.<\/strong><\/p>\n","protected":false},"excerpt":{"rendered":"<p>Robert M. Barrack | Gordon Rees Scully Mansukhani In\u00a0United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials&hellip; <a class=\"more-link\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/\">Continue reading <span class=\"screen-reader-text\">The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier<\/span><\/a><\/p>\n","protected":false},"author":1,"featured_media":0,"comment_status":"open","ping_status":"open","sticky":false,"template":"","format":"standard","meta":{"jetpack_post_was_ever_published":false,"_jetpack_newsletter_access":"","_jetpack_dont_email_post_to_subs":false,"_jetpack_newsletter_tier_id":0,"_jetpack_memberships_contains_paywalled_content":false,"_jetpack_memberships_contains_paid_content":false,"footnotes":"","jetpack_publicize_message":"","jetpack_publicize_feature_enabled":true,"jetpack_social_post_already_shared":true,"jetpack_social_options":{"image_generator_settings":{"template":"highway","enabled":false},"version":2}},"categories":[14],"tags":[9895,12,9910],"class_list":["post-899908","post","type-post","status-publish","format-standard","hentry","category-construction-2","tag-advise-consult","tag-construction","tag-material-suppliers","entry"],"jetpack_publicize_connections":[],"yoast_head":"<!-- This site is optimized with the Yoast SEO plugin v25.0 - https:\/\/yoast.com\/wordpress\/plugins\/seo\/ -->\n<title>The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier - Advise &amp; Consult, Inc.<\/title>\n<meta name=\"description\" content=\"The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects.\" \/>\n<meta name=\"robots\" content=\"index, follow, max-snippet:-1, max-image-preview:large, max-video-preview:-1\" \/>\n<link rel=\"canonical\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/\" \/>\n<meta property=\"og:locale\" content=\"en_US\" \/>\n<meta property=\"og:type\" content=\"article\" \/>\n<meta property=\"og:title\" content=\"The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier - Advise &amp; Consult, Inc.\" \/>\n<meta property=\"og:description\" content=\"The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects.\" \/>\n<meta property=\"og:url\" content=\"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/\" \/>\n<meta property=\"og:site_name\" content=\"Advise &amp; Consult, Inc.\" \/>\n<meta property=\"article:publisher\" content=\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\" \/>\n<meta property=\"article:published_time\" content=\"2022-05-04T21:12:12+00:00\" \/>\n<meta property=\"article:modified_time\" content=\"2022-05-04T21:12:16+00:00\" \/>\n<meta name=\"author\" content=\"admin\" \/>\n<meta name=\"twitter:card\" content=\"summary_large_image\" \/>\n<meta name=\"twitter:creator\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:site\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:label1\" content=\"Written by\" \/>\n\t<meta name=\"twitter:data1\" content=\"admin\" \/>\n\t<meta name=\"twitter:label2\" content=\"Est. reading time\" \/>\n\t<meta name=\"twitter:data2\" content=\"6 minutes\" \/>\n<script type=\"application\/ld+json\" class=\"yoast-schema-graph\">{\"@context\":\"https:\/\/schema.org\",\"@graph\":[{\"@type\":\"Article\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/#article\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/\"},\"author\":{\"name\":\"admin\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\"},\"headline\":\"The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier\",\"datePublished\":\"2022-05-04T21:12:12+00:00\",\"dateModified\":\"2022-05-04T21:12:16+00:00\",\"mainEntityOfPage\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/\"},\"wordCount\":1132,\"commentCount\":0,\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"keywords\":[\"Advise &amp; Consult\",\"construction\",\"Material Suppliers\"],\"articleSection\":[\"Construction\"],\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"CommentAction\",\"name\":\"Comment\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/#respond\"]}]},{\"@type\":\"WebPage\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/\",\"name\":\"The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier - Advise &amp; Consult, Inc.\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\"},\"datePublished\":\"2022-05-04T21:12:12+00:00\",\"dateModified\":\"2022-05-04T21:12:16+00:00\",\"description\":\"The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects.\",\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"ReadAction\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/\"]}]},{\"@type\":\"WebSite\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"name\":\"Advise &amp; Consult, Inc.\",\"description\":\"Construction Expert Witnesses\",\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"potentialAction\":[{\"@type\":\"SearchAction\",\"target\":{\"@type\":\"EntryPoint\",\"urlTemplate\":\"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}\"},\"query-input\":{\"@type\":\"PropertyValueSpecification\",\"valueRequired\":true,\"valueName\":\"search_term_string\"}}],\"inLanguage\":\"en-US\"},{\"@type\":\"Organization\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\",\"name\":\"Advise & Consult\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"logo\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"contentUrl\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"width\":162,\"height\":75,\"caption\":\"Advise & Consult\"},\"image\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\"},\"sameAs\":[\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\",\"https:\/\/x.com\/adviseconsult\",\"https:\/\/www.linkedin.com\/company-beta\/204526\/\",\"https:\/\/www.youtube.com\/user\/MrConstructionExpert\"]},{\"@type\":\"Person\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\",\"name\":\"admin\",\"image\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/\",\"url\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"contentUrl\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"caption\":\"admin\"},\"sameAs\":[\"http:\/\/www.expertwitnessinconstruction.com\"]}]}<\/script>\n<!-- \/ Yoast SEO plugin. -->","yoast_head_json":{"title":"The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier - Advise &amp; Consult, Inc.","description":"The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects.","robots":{"index":"index","follow":"follow","max-snippet":"max-snippet:-1","max-image-preview":"max-image-preview:large","max-video-preview":"max-video-preview:-1"},"canonical":"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/","og_locale":"en_US","og_type":"article","og_title":"The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier - Advise &amp; Consult, Inc.","og_description":"The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects.","og_url":"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/","og_site_name":"Advise &amp; Consult, Inc.","article_publisher":"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","article_published_time":"2022-05-04T21:12:12+00:00","article_modified_time":"2022-05-04T21:12:16+00:00","author":"admin","twitter_card":"summary_large_image","twitter_creator":"@adviseconsult","twitter_site":"@adviseconsult","twitter_misc":{"Written by":"admin","Est. reading time":"6 minutes"},"schema":{"@context":"https:\/\/schema.org","@graph":[{"@type":"Article","@id":"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/#article","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/"},"author":{"name":"admin","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7"},"headline":"The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier","datePublished":"2022-05-04T21:12:12+00:00","dateModified":"2022-05-04T21:12:16+00:00","mainEntityOfPage":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/"},"wordCount":1132,"commentCount":0,"publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"keywords":["Advise &amp; Consult","construction","Material Suppliers"],"articleSection":["Construction"],"inLanguage":"en-US","potentialAction":[{"@type":"CommentAction","name":"Comment","target":["https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/#respond"]}]},{"@type":"WebPage","@id":"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/","name":"The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier - Advise &amp; Consult, Inc.","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website"},"datePublished":"2022-05-04T21:12:12+00:00","dateModified":"2022-05-04T21:12:16+00:00","description":"The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects.","inLanguage":"en-US","potentialAction":[{"@type":"ReadAction","target":["https:\/\/www.myconstructionexpert.com\/blog\/delivery-of-materials-accelerated-schedule\/"]}]},{"@type":"WebSite","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website","url":"https:\/\/www.myconstructionexpert.com\/blog\/","name":"Advise &amp; Consult, Inc.","description":"Construction Expert Witnesses","publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"potentialAction":[{"@type":"SearchAction","target":{"@type":"EntryPoint","urlTemplate":"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}"},"query-input":{"@type":"PropertyValueSpecification","valueRequired":true,"valueName":"search_term_string"}}],"inLanguage":"en-US"},{"@type":"Organization","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization","name":"Advise & Consult","url":"https:\/\/www.myconstructionexpert.com\/blog\/","logo":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","contentUrl":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","width":162,"height":75,"caption":"Advise & Consult"},"image":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/"},"sameAs":["https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","https:\/\/x.com\/adviseconsult","https:\/\/www.linkedin.com\/company-beta\/204526\/","https:\/\/www.youtube.com\/user\/MrConstructionExpert"]},{"@type":"Person","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7","name":"admin","image":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/","url":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","contentUrl":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","caption":"admin"},"sameAs":["http:\/\/www.expertwitnessinconstruction.com"]}]}},"jetpack_featured_media_url":"","jetpack_sharing_enabled":true,"jetpack_shortlink":"https:\/\/wp.me\/p2ztG6-3M6E","jetpack_likes_enabled":true,"_links":{"self":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/899908","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/users\/1"}],"replies":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/comments?post=899908"}],"version-history":[{"count":1,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/899908\/revisions"}],"predecessor-version":[{"id":899909,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/899908\/revisions\/899909"}],"wp:attachment":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/media?parent=899908"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/categories?post=899908"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/tags?post=899908"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}