{"id":901819,"date":"2023-11-02T14:42:22","date_gmt":"2023-11-02T20:42:22","guid":{"rendered":"https:\/\/www.myconstructionexpert.com\/blog\/?p=901819"},"modified":"2023-11-02T14:42:28","modified_gmt":"2023-11-02T20:42:28","slug":"wrongful-termination-counterclaim-dismissed","status":"publish","type":"post","link":"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/","title":{"rendered":"Court Affirms Dismissal of Subcontractor\u2019s Wrongful Termination Counterclaim and Clarifies Scope of Upcoming Trial on Damages"},"content":{"rendered":"\n<p>John Mark Goodman | <a href=\"https:\/\/www.buildsmartbradley.com\/2023\/10\/court-affirms-dismissal-of-subcontractors-wrongful-termination-counterclaim-and-clarifies-scope-of-upcoming-trial-on-damages\/?utm_source=Bradley+Arant+Boult+Cummings+LLP+-+BuildSmart&amp;utm_campaign=e9bf3bc924-RSS_EMAIL_CAMPAIGN&amp;utm_medium=email&amp;utm_term=0_b504caf31b-e9bf3bc924-78863422\" target=\"_blank\" rel=\"noreferrer noopener nofollow\">BuildSmart<\/a><\/p>\n\n\n\n<p>Back in April we\u00a0<a href=\"https:\/\/www.bradley.com\/insights\/publications\/2023\/04\/no-written-notice-of-delay-big-problem-court-sides-with-contractor-in-termination-dispute\" target=\"_blank\" rel=\"noreferrer noopener\">examined<\/a>\u00a0the court\u2019s decision in\u00a0<em>Boldt v. Black &amp; Veatch<\/em>, which dismissed a subcontractor\u2019s counterclaim for <a href=\"https:\/\/www.myconstructionexpert.com\/blog\/termination-limitation-liability-clauses-proceed-caution\/\">wrongful termination<\/a> on a 60-turbine wind farm project. As you may recall, the subcontractor hired to erect the turbines alleged that it was wrongfully terminated for delays that were not its fault but were the fault of the contractor and the wind turbine manufacturer.\u00a0The court rejected that excuse because the subcontractor had not availed itself of its contractual remedies to obtain schedule relief for delays that were not its fault.<\/p>\n\n\n\n<p>Since our last post, the subcontractor filed a motion asking the court to reconsider its prior ruling. That motion was denied in a\u00a0<a href=\"https:\/\/www.buildsmartbradley.com\/wp-content\/uploads\/sites\/34\/2023\/10\/2023.10.02-Boldt-Order-on-Motion-to-Reconsider.pdf\" target=\"_blank\" rel=\"noreferrer noopener nofollow\">decision<\/a>\u00a0released earlier this month that proved to be a double whammy for the subcontractor.\u00a0In addition to reaffirming its dismissal of the subcontractor\u2019s wrongful termination, the court held that the upcoming trial on the contractor\u2019s corresponding claim for breach of contract will be a damages-only trial since liability has effectively already been decided.\u00a0Here is what the court said about that:<\/p>\n\n\n\n<blockquote class=\"wp-block-quote is-layout-flow wp-block-quote-is-layout-flow\">\n<p>Ultimately, this case is about whether BVCI had cause to terminate Boldt from the Project for cause. It is undisputed that shortly after Boldt began its work on the Project, it fell behind the Construction Schedule. Nor does Boldt dispute that it failed to timely perform critical tasks that were entirely within its control. In this case, Boldt has tried to shift blame for the delays to both BVCI and the Project\u2019s turbine vendor. However, in granting summary judgment in favor of BVCI as to Boldt\u2019s breach of contract claim, the Court determined that the Subcontract set forth certain procedures for Boldt to follow during the course of its work to demonstrate delays outside of its control and to protect itself from liability for such delays. Boldt has failed to show that it followed those procedures. Consequently, BVCI had good reason to conclude that Boldt was in default of its Subcontract obligations. And when Boldt proved unable to get its work back on track, BVCI had the right to terminate Boldt for cause. Stated succinctly, BVCI properly terminated Boldt for cause and there is no jury issue regarding Boldt\u2019s claim for wrongful termination.<\/p>\n<\/blockquote>\n\n\n\n<blockquote class=\"wp-block-quote is-layout-flow wp-block-quote-is-layout-flow\">\n<p>Although BVCI did not move for summary judgment as to its own counterclaim, the Court\u2019s ruling on the motions for summary judgment has all but decided Boldt\u2019s liability. All that remains for trial is a determination of BVCI\u2019s damages. One category of damages that BVCI seeks is damages for delayed Project completion. Boldt contends that it should be able to raise the issue of whether it was truly responsible for the Project\u2019s delay at least as to those damages. However, the Court will not allow a trial on damages to turn into a liability trial regarding who was truly responsible for the delays to the Construction Schedule. The Subcontract provides that Boldt \u201cshall not be responsible or liable\u201d for delays in completing its work insofar as the delays were caused by an Owner and\/or Purchaser-Caused Delay or a Turbine Vendor-Caused Delay.&nbsp; Because Boldt did not take the steps necessary to establish either delay and failed to fulfill its own obligations under the Subcontract, Boldt will be fully responsible to BVCI for any damages resulting from its termination for cause.<\/p>\n<\/blockquote>\n\n\n\n<p>The trial on the contractor\u2019s breach of contract damages is set to begin October 30.<\/p>\n\n\n\n<hr class=\"wp-block-separator has-alpha-channel-opacity\"\/>\n\n\n\n<p><strong>When one of your cases is in need of a construction expert, estimates, insurance appraisal or umpire services in defect or insurance disputes &#8211; please call Advise &amp; Consult, Inc. at 888.684.8305, or email <a href=\"mailto:experts@adviseandconsult.net\">experts@adviseandconsult.net<\/a>.<\/strong><\/p>\n","protected":false},"excerpt":{"rendered":"<p>John Mark Goodman | BuildSmart Back in April we\u00a0examined\u00a0the court\u2019s decision in\u00a0Boldt v. Black &amp; Veatch, which dismissed a subcontractor\u2019s counterclaim for wrongful termination on a 60-turbine wind farm project. As you may recall, the subcontractor hired to erect the turbines alleged that it was wrongfully terminated for delays that were not its fault but&hellip; <a class=\"more-link\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/\">Continue reading <span class=\"screen-reader-text\">Court Affirms Dismissal of Subcontractor\u2019s Wrongful Termination Counterclaim and Clarifies Scope of Upcoming Trial on Damages<\/span><\/a><\/p>\n","protected":false},"author":1,"featured_media":0,"comment_status":"open","ping_status":"open","sticky":false,"template":"","format":"standard","meta":{"jetpack_post_was_ever_published":false,"_jetpack_newsletter_access":"","_jetpack_dont_email_post_to_subs":false,"_jetpack_newsletter_tier_id":0,"_jetpack_memberships_contains_paywalled_content":false,"_jetpack_memberships_contains_paid_content":false,"footnotes":"","jetpack_publicize_message":"","jetpack_publicize_feature_enabled":true,"jetpack_social_post_already_shared":true,"jetpack_social_options":{"image_generator_settings":{"template":"highway","enabled":false},"version":2}},"categories":[9],"tags":[9895,224,11866],"class_list":["post-901819","post","type-post","status-publish","format-standard","hentry","category-construction-contracts","tag-advise-consult","tag-construction-contract","tag-wrongful-termination-claim","entry"],"jetpack_publicize_connections":[],"yoast_head":"<!-- This site is optimized with the Yoast SEO plugin v25.0 - https:\/\/yoast.com\/wordpress\/plugins\/seo\/ -->\n<title>Court Affirms Dismissal of Subcontractor\u2019s Wrongful Termination Counterclaim and Clarifies Scope of Upcoming Trial on Damages - Advise &amp; Consult, Inc.<\/title>\n<meta name=\"description\" content=\"subcontractor\u2019s wrongful termination, the court held that the upcoming trial on the contractor\u2019s corresponding claim for breach of contract\" \/>\n<meta name=\"robots\" content=\"index, follow, max-snippet:-1, max-image-preview:large, max-video-preview:-1\" \/>\n<link rel=\"canonical\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/\" \/>\n<meta property=\"og:locale\" content=\"en_US\" \/>\n<meta property=\"og:type\" content=\"article\" \/>\n<meta property=\"og:title\" content=\"Court Affirms Dismissal of Subcontractor\u2019s Wrongful Termination Counterclaim and Clarifies Scope of Upcoming Trial on Damages - Advise &amp; Consult, Inc.\" \/>\n<meta property=\"og:description\" content=\"subcontractor\u2019s wrongful termination, the court held that the upcoming trial on the contractor\u2019s corresponding claim for breach of contract\" \/>\n<meta property=\"og:url\" content=\"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/\" \/>\n<meta property=\"og:site_name\" content=\"Advise &amp; Consult, Inc.\" \/>\n<meta property=\"article:publisher\" content=\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\" \/>\n<meta property=\"article:published_time\" content=\"2023-11-02T20:42:22+00:00\" \/>\n<meta property=\"article:modified_time\" content=\"2023-11-02T20:42:28+00:00\" \/>\n<meta name=\"author\" content=\"admin\" \/>\n<meta name=\"twitter:card\" content=\"summary_large_image\" \/>\n<meta name=\"twitter:creator\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:site\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:label1\" content=\"Written by\" \/>\n\t<meta name=\"twitter:data1\" content=\"admin\" \/>\n\t<meta name=\"twitter:label2\" content=\"Est. reading time\" \/>\n\t<meta name=\"twitter:data2\" content=\"1 minute\" \/>\n<script type=\"application\/ld+json\" class=\"yoast-schema-graph\">{\"@context\":\"https:\/\/schema.org\",\"@graph\":[{\"@type\":\"Article\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/#article\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/\"},\"author\":{\"name\":\"admin\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\"},\"headline\":\"Court Affirms Dismissal of Subcontractor\u2019s Wrongful Termination Counterclaim and Clarifies Scope of Upcoming Trial on Damages\",\"datePublished\":\"2023-11-02T20:42:22+00:00\",\"dateModified\":\"2023-11-02T20:42:28+00:00\",\"mainEntityOfPage\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/\"},\"wordCount\":633,\"commentCount\":0,\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"keywords\":[\"Advise &amp; Consult\",\"Construction Contract\",\"Wrongful Termination Claim\"],\"articleSection\":[\"Construction Contracts\"],\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"CommentAction\",\"name\":\"Comment\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/#respond\"]}]},{\"@type\":\"WebPage\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/\",\"name\":\"Court Affirms Dismissal of Subcontractor\u2019s Wrongful Termination Counterclaim and Clarifies Scope of Upcoming Trial on Damages - Advise &amp; Consult, Inc.\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\"},\"datePublished\":\"2023-11-02T20:42:22+00:00\",\"dateModified\":\"2023-11-02T20:42:28+00:00\",\"description\":\"subcontractor\u2019s wrongful termination, the court held that the upcoming trial on the contractor\u2019s corresponding claim for breach of contract\",\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"ReadAction\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/\"]}]},{\"@type\":\"WebSite\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"name\":\"Advise &amp; Consult, Inc.\",\"description\":\"Construction Expert Witnesses\",\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"potentialAction\":[{\"@type\":\"SearchAction\",\"target\":{\"@type\":\"EntryPoint\",\"urlTemplate\":\"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}\"},\"query-input\":{\"@type\":\"PropertyValueSpecification\",\"valueRequired\":true,\"valueName\":\"search_term_string\"}}],\"inLanguage\":\"en-US\"},{\"@type\":\"Organization\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\",\"name\":\"Advise & Consult\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"logo\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"contentUrl\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"width\":162,\"height\":75,\"caption\":\"Advise & Consult\"},\"image\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\"},\"sameAs\":[\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\",\"https:\/\/x.com\/adviseconsult\",\"https:\/\/www.linkedin.com\/company-beta\/204526\/\",\"https:\/\/www.youtube.com\/user\/MrConstructionExpert\"]},{\"@type\":\"Person\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\",\"name\":\"admin\",\"image\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/\",\"url\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"contentUrl\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"caption\":\"admin\"},\"sameAs\":[\"http:\/\/www.expertwitnessinconstruction.com\"]}]}<\/script>\n<!-- \/ Yoast SEO plugin. -->","yoast_head_json":{"title":"Court Affirms Dismissal of Subcontractor\u2019s Wrongful Termination Counterclaim and Clarifies Scope of Upcoming Trial on Damages - Advise &amp; Consult, Inc.","description":"subcontractor\u2019s wrongful termination, the court held that the upcoming trial on the contractor\u2019s corresponding claim for breach of contract","robots":{"index":"index","follow":"follow","max-snippet":"max-snippet:-1","max-image-preview":"max-image-preview:large","max-video-preview":"max-video-preview:-1"},"canonical":"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/","og_locale":"en_US","og_type":"article","og_title":"Court Affirms Dismissal of Subcontractor\u2019s Wrongful Termination Counterclaim and Clarifies Scope of Upcoming Trial on Damages - Advise &amp; Consult, Inc.","og_description":"subcontractor\u2019s wrongful termination, the court held that the upcoming trial on the contractor\u2019s corresponding claim for breach of contract","og_url":"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/","og_site_name":"Advise &amp; Consult, Inc.","article_publisher":"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","article_published_time":"2023-11-02T20:42:22+00:00","article_modified_time":"2023-11-02T20:42:28+00:00","author":"admin","twitter_card":"summary_large_image","twitter_creator":"@adviseconsult","twitter_site":"@adviseconsult","twitter_misc":{"Written by":"admin","Est. reading time":"1 minute"},"schema":{"@context":"https:\/\/schema.org","@graph":[{"@type":"Article","@id":"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/#article","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/"},"author":{"name":"admin","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7"},"headline":"Court Affirms Dismissal of Subcontractor\u2019s Wrongful Termination Counterclaim and Clarifies Scope of Upcoming Trial on Damages","datePublished":"2023-11-02T20:42:22+00:00","dateModified":"2023-11-02T20:42:28+00:00","mainEntityOfPage":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/"},"wordCount":633,"commentCount":0,"publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"keywords":["Advise &amp; Consult","Construction Contract","Wrongful Termination Claim"],"articleSection":["Construction Contracts"],"inLanguage":"en-US","potentialAction":[{"@type":"CommentAction","name":"Comment","target":["https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/#respond"]}]},{"@type":"WebPage","@id":"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/","name":"Court Affirms Dismissal of Subcontractor\u2019s Wrongful Termination Counterclaim and Clarifies Scope of Upcoming Trial on Damages - Advise &amp; Consult, Inc.","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website"},"datePublished":"2023-11-02T20:42:22+00:00","dateModified":"2023-11-02T20:42:28+00:00","description":"subcontractor\u2019s wrongful termination, the court held that the upcoming trial on the contractor\u2019s corresponding claim for breach of contract","inLanguage":"en-US","potentialAction":[{"@type":"ReadAction","target":["https:\/\/www.myconstructionexpert.com\/blog\/wrongful-termination-counterclaim-dismissed\/"]}]},{"@type":"WebSite","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website","url":"https:\/\/www.myconstructionexpert.com\/blog\/","name":"Advise &amp; Consult, Inc.","description":"Construction Expert Witnesses","publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"potentialAction":[{"@type":"SearchAction","target":{"@type":"EntryPoint","urlTemplate":"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}"},"query-input":{"@type":"PropertyValueSpecification","valueRequired":true,"valueName":"search_term_string"}}],"inLanguage":"en-US"},{"@type":"Organization","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization","name":"Advise & Consult","url":"https:\/\/www.myconstructionexpert.com\/blog\/","logo":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","contentUrl":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","width":162,"height":75,"caption":"Advise & Consult"},"image":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/"},"sameAs":["https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","https:\/\/x.com\/adviseconsult","https:\/\/www.linkedin.com\/company-beta\/204526\/","https:\/\/www.youtube.com\/user\/MrConstructionExpert"]},{"@type":"Person","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7","name":"admin","image":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/","url":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","contentUrl":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","caption":"admin"},"sameAs":["http:\/\/www.expertwitnessinconstruction.com"]}]}},"jetpack_featured_media_url":"","jetpack_sharing_enabled":true,"jetpack_shortlink":"https:\/\/wp.me\/p2ztG6-3MBt","jetpack_likes_enabled":true,"_links":{"self":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/901819","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/users\/1"}],"replies":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/comments?post=901819"}],"version-history":[{"count":1,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/901819\/revisions"}],"predecessor-version":[{"id":901820,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/901819\/revisions\/901820"}],"wp:attachment":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/media?parent=901819"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/categories?post=901819"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/tags?post=901819"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}