{"id":904598,"date":"2025-07-23T15:58:07","date_gmt":"2025-07-23T21:58:07","guid":{"rendered":"https:\/\/www.myconstructionexpert.com\/blog\/?p=904598"},"modified":"2025-07-23T15:58:13","modified_gmt":"2025-07-23T21:58:13","slug":"compensable-delay-or-act-of-god","status":"publish","type":"post","link":"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/","title":{"rendered":"The Bottom Line: Cost and Pricing Updates | Act of God or Compensable Delay?"},"content":{"rendered":"\n<p>Stephanie Harden | <a href=\"https:\/\/governmentcontractsnavigator.com\/2025\/06\/10\/the-bottom-line-cost-and-pricing-updates-act-of-god-or-compensable-delay\/\" target=\"_blank\" rel=\"noreferrer noopener nofollow\">Blank Rome<\/a><\/p>\n\n\n\n<p>Welcome to&nbsp;<strong><em>The Bottom Line: Cost and Pricing Updates,&nbsp;<\/em><\/strong>a new series covering what contractors should know about recent cost and pricing disputes\u2014without the long read!<\/p>\n\n\n\n<p>For our inaugural post, we present:<\/p>\n\n\n\n<p><em>Appeal of Gideon Contracting, LLC<\/em>, ASBCA No. 63561 (May 12, 2025)<\/p>\n\n\n\n<p><strong>The Bottom Line:<\/strong>&nbsp;When the Government orders a suspension of work due to an \u201cact of God,\u201d it may still be on the hook for the resulting increased costs under the Suspension of Work clause if it proximately causes an unreasonable delay. Here, the Government proximately caused the delay at issue through its management of water drainage through a lake and dam, including through controlled releases of water, and the Armed Services Board of Contract Appeals (\u201cASBCA\u201d or \u201cthe Board\u201d) found a portion of the delay to be unreasonable.<\/p>\n\n\n\n<p><strong>Key points of interest:<\/strong><\/p>\n\n\n\n<ul class=\"wp-block-list\">\n<li>Generally, \u201cacts of God\u201d entitle contractors to additional time, but not additional compensation. However, the distinguishing feature entitling Gideon to additional compensation here was that the Government controlled the release of floodwaters via a drainage management system. Thus, the flooding was not caused solely by rainfall, as the Government argued, but rather, by the Government\u2019s release of floodwater.<\/li>\n\n\n\n<li>Gideon was not entitled to damages for the entire suspension period, however, because the contract specified when and how water releases would occur. Therefore, Gideon was only entitled to compensation for portions of the suspension that were found to be \u201cunreasonable\u201d (or as described by the Board, inexplicable).<\/li>\n<\/ul>\n\n\n\n<p>Contractors facing <a href=\"https:\/\/www.myconstructionexpert.com\/blog\/fixed-price-contract-delays-and-suspension\/\">suspensions of work<\/a> should carefully evaluate whether their contracts may entitle them to relief where at least a portion of such suspensions are \u201cunreasonable.\u201d<\/p>\n\n\n\n<hr class=\"wp-block-separator has-alpha-channel-opacity\"\/>\n\n\n\n<p><strong>When one of your cases is in need of a construction expert, estimates, insurance appraisal or umpire services in defect or insurance disputes &#8211; please call Advise &amp; Consult, Inc. at 888.684.8305, or email <a href=\"mailto:experts@adviseandconsult.ne\">experts@adviseandconsult.ne<\/a>t.<\/strong><\/p>\n","protected":false},"excerpt":{"rendered":"<p>Stephanie Harden | Blank Rome Welcome to&nbsp;The Bottom Line: Cost and Pricing Updates,&nbsp;a new series covering what contractors should know about recent cost and pricing disputes\u2014without the long read! For our inaugural post, we present: Appeal of Gideon Contracting, LLC, ASBCA No. 63561 (May 12, 2025) The Bottom Line:&nbsp;When the Government orders a suspension of&hellip; <a class=\"more-link\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/\">Continue reading <span class=\"screen-reader-text\">The Bottom Line: Cost and Pricing Updates | Act of God or Compensable Delay?<\/span><\/a><\/p>\n","protected":false},"author":1,"featured_media":0,"comment_status":"open","ping_status":"open","sticky":false,"template":"","format":"standard","meta":{"jetpack_post_was_ever_published":false,"_jetpack_newsletter_access":"","_jetpack_dont_email_post_to_subs":false,"_jetpack_newsletter_tier_id":0,"_jetpack_memberships_contains_paywalled_content":false,"_jetpack_memberships_contains_paid_content":false,"footnotes":"","jetpack_publicize_message":"","jetpack_publicize_feature_enabled":true,"jetpack_social_post_already_shared":true,"jetpack_social_options":{"image_generator_settings":{"template":"highway","enabled":false},"version":2}},"categories":[9],"tags":[9895,12196,224,9831],"class_list":["post-904598","post","type-post","status-publish","format-standard","hentry","category-construction-contracts","tag-advise-consult","tag-compensable-delay","tag-construction-contract","tag-delay-claims","entry"],"jetpack_publicize_connections":[],"yoast_head":"<!-- This site is optimized with the Yoast SEO plugin v25.0 - https:\/\/yoast.com\/wordpress\/plugins\/seo\/ -->\n<title>The Bottom Line: Cost and Pricing Updates | Act of God or Compensable Delay? - Advise &amp; Consult, Inc.<\/title>\n<meta name=\"description\" content=\"Contractors facing suspensions of work should see whether their contracts entitle them to relief where at least a portion are \u201cunreasonable.\u201d\" \/>\n<meta name=\"robots\" content=\"index, follow, max-snippet:-1, max-image-preview:large, max-video-preview:-1\" \/>\n<link rel=\"canonical\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/\" \/>\n<meta property=\"og:locale\" content=\"en_US\" \/>\n<meta property=\"og:type\" content=\"article\" \/>\n<meta property=\"og:title\" content=\"The Bottom Line: Cost and Pricing Updates | Act of God or Compensable Delay? - Advise &amp; Consult, Inc.\" \/>\n<meta property=\"og:description\" content=\"Contractors facing suspensions of work should see whether their contracts entitle them to relief where at least a portion are \u201cunreasonable.\u201d\" \/>\n<meta property=\"og:url\" content=\"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/\" \/>\n<meta property=\"og:site_name\" content=\"Advise &amp; Consult, Inc.\" \/>\n<meta property=\"article:publisher\" content=\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\" \/>\n<meta property=\"article:published_time\" content=\"2025-07-23T21:58:07+00:00\" \/>\n<meta property=\"article:modified_time\" content=\"2025-07-23T21:58:13+00:00\" \/>\n<meta name=\"author\" content=\"admin\" \/>\n<meta name=\"twitter:card\" content=\"summary_large_image\" \/>\n<meta name=\"twitter:creator\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:site\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:label1\" content=\"Written by\" \/>\n\t<meta name=\"twitter:data1\" content=\"admin\" \/>\n\t<meta name=\"twitter:label2\" content=\"Est. reading time\" \/>\n\t<meta name=\"twitter:data2\" content=\"2 minutes\" \/>\n<script type=\"application\/ld+json\" class=\"yoast-schema-graph\">{\"@context\":\"https:\/\/schema.org\",\"@graph\":[{\"@type\":\"Article\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/#article\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/\"},\"author\":{\"name\":\"admin\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\"},\"headline\":\"The Bottom Line: Cost and Pricing Updates | Act of God or Compensable Delay?\",\"datePublished\":\"2025-07-23T21:58:07+00:00\",\"dateModified\":\"2025-07-23T21:58:13+00:00\",\"mainEntityOfPage\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/\"},\"wordCount\":323,\"commentCount\":0,\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"keywords\":[\"Advise &amp; Consult\",\"Compensable Delay\",\"Construction Contract\",\"Delay Claims\"],\"articleSection\":[\"Construction Contracts\"],\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"CommentAction\",\"name\":\"Comment\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/#respond\"]}]},{\"@type\":\"WebPage\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/\",\"name\":\"The Bottom Line: Cost and Pricing Updates | Act of God or Compensable Delay? - Advise &amp; Consult, Inc.\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\"},\"datePublished\":\"2025-07-23T21:58:07+00:00\",\"dateModified\":\"2025-07-23T21:58:13+00:00\",\"description\":\"Contractors facing suspensions of work should see whether their contracts entitle them to relief where at least a portion are \u201cunreasonable.\u201d\",\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"ReadAction\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/\"]}]},{\"@type\":\"WebSite\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"name\":\"Advise &amp; Consult, Inc.\",\"description\":\"Construction Expert Witnesses\",\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"potentialAction\":[{\"@type\":\"SearchAction\",\"target\":{\"@type\":\"EntryPoint\",\"urlTemplate\":\"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}\"},\"query-input\":{\"@type\":\"PropertyValueSpecification\",\"valueRequired\":true,\"valueName\":\"search_term_string\"}}],\"inLanguage\":\"en-US\"},{\"@type\":\"Organization\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\",\"name\":\"Advise & Consult\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"logo\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"contentUrl\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"width\":162,\"height\":75,\"caption\":\"Advise & Consult\"},\"image\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\"},\"sameAs\":[\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\",\"https:\/\/x.com\/adviseconsult\",\"https:\/\/www.linkedin.com\/company-beta\/204526\/\",\"https:\/\/www.youtube.com\/user\/MrConstructionExpert\"]},{\"@type\":\"Person\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\",\"name\":\"admin\",\"image\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/\",\"url\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"contentUrl\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"caption\":\"admin\"},\"sameAs\":[\"http:\/\/www.expertwitnessinconstruction.com\"]}]}<\/script>\n<!-- \/ Yoast SEO plugin. -->","yoast_head_json":{"title":"The Bottom Line: Cost and Pricing Updates | Act of God or Compensable Delay? - Advise &amp; Consult, Inc.","description":"Contractors facing suspensions of work should see whether their contracts entitle them to relief where at least a portion are \u201cunreasonable.\u201d","robots":{"index":"index","follow":"follow","max-snippet":"max-snippet:-1","max-image-preview":"max-image-preview:large","max-video-preview":"max-video-preview:-1"},"canonical":"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/","og_locale":"en_US","og_type":"article","og_title":"The Bottom Line: Cost and Pricing Updates | Act of God or Compensable Delay? - Advise &amp; Consult, Inc.","og_description":"Contractors facing suspensions of work should see whether their contracts entitle them to relief where at least a portion are \u201cunreasonable.\u201d","og_url":"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/","og_site_name":"Advise &amp; Consult, Inc.","article_publisher":"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","article_published_time":"2025-07-23T21:58:07+00:00","article_modified_time":"2025-07-23T21:58:13+00:00","author":"admin","twitter_card":"summary_large_image","twitter_creator":"@adviseconsult","twitter_site":"@adviseconsult","twitter_misc":{"Written by":"admin","Est. reading time":"2 minutes"},"schema":{"@context":"https:\/\/schema.org","@graph":[{"@type":"Article","@id":"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/#article","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/"},"author":{"name":"admin","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7"},"headline":"The Bottom Line: Cost and Pricing Updates | Act of God or Compensable Delay?","datePublished":"2025-07-23T21:58:07+00:00","dateModified":"2025-07-23T21:58:13+00:00","mainEntityOfPage":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/"},"wordCount":323,"commentCount":0,"publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"keywords":["Advise &amp; Consult","Compensable Delay","Construction Contract","Delay Claims"],"articleSection":["Construction Contracts"],"inLanguage":"en-US","potentialAction":[{"@type":"CommentAction","name":"Comment","target":["https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/#respond"]}]},{"@type":"WebPage","@id":"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/","name":"The Bottom Line: Cost and Pricing Updates | Act of God or Compensable Delay? - Advise &amp; Consult, Inc.","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website"},"datePublished":"2025-07-23T21:58:07+00:00","dateModified":"2025-07-23T21:58:13+00:00","description":"Contractors facing suspensions of work should see whether their contracts entitle them to relief where at least a portion are \u201cunreasonable.\u201d","inLanguage":"en-US","potentialAction":[{"@type":"ReadAction","target":["https:\/\/www.myconstructionexpert.com\/blog\/compensable-delay-or-act-of-god\/"]}]},{"@type":"WebSite","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website","url":"https:\/\/www.myconstructionexpert.com\/blog\/","name":"Advise &amp; Consult, Inc.","description":"Construction Expert Witnesses","publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"potentialAction":[{"@type":"SearchAction","target":{"@type":"EntryPoint","urlTemplate":"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}"},"query-input":{"@type":"PropertyValueSpecification","valueRequired":true,"valueName":"search_term_string"}}],"inLanguage":"en-US"},{"@type":"Organization","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization","name":"Advise & Consult","url":"https:\/\/www.myconstructionexpert.com\/blog\/","logo":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","contentUrl":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","width":162,"height":75,"caption":"Advise & Consult"},"image":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/"},"sameAs":["https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","https:\/\/x.com\/adviseconsult","https:\/\/www.linkedin.com\/company-beta\/204526\/","https:\/\/www.youtube.com\/user\/MrConstructionExpert"]},{"@type":"Person","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7","name":"admin","image":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/","url":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","contentUrl":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","caption":"admin"},"sameAs":["http:\/\/www.expertwitnessinconstruction.com"]}]}},"jetpack_featured_media_url":"","jetpack_sharing_enabled":true,"jetpack_shortlink":"https:\/\/wp.me\/p2ztG6-3Nki","jetpack_likes_enabled":true,"_links":{"self":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/904598","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/users\/1"}],"replies":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/comments?post=904598"}],"version-history":[{"count":1,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/904598\/revisions"}],"predecessor-version":[{"id":904599,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/904598\/revisions\/904599"}],"wp:attachment":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/media?parent=904598"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/categories?post=904598"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/tags?post=904598"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}