{"id":906331,"date":"2026-11-10T15:53:55","date_gmt":"2026-11-10T22:53:55","guid":{"rendered":"https:\/\/www.myconstructionexpert.com\/blog\/?p=906331"},"modified":"2026-11-10T15:53:58","modified_gmt":"2026-11-10T22:53:58","slug":"fraud-claims-not-barred-by-contractual-waiver","status":"publish","type":"post","link":"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/","title":{"rendered":"Fraud Claims Not Barred by Contractual Waiver: Tennessee Court Affirms Punitive Damages Award Against General Contractor"},"content":{"rendered":"\n<p>James Daniel and John Mark Goodman | <a href=\"https:\/\/www.buildsmartbradley.com\/2026\/11\/fraud-claims-not-barred-by-contractual-waiver-tennessee-court-affirms-punitive-damages-award-against-general-contractor\/?utm_source=Bradley+Arant+Boult+Cummings+LLP+-+BuildSmart&amp;utm_campaign=fd2d1cd6be-RSS_EMAIL_CAMPAIGN&amp;utm_medium=email&amp;utm_term=0_b504caf31b-fd2d1cd6be-78863422\" target=\"_blank\" rel=\"noreferrer noopener nofollow\">BuildSmart<\/a><\/p>\n\n\n\n<p id=\"the-tennessee-court-of-appeals-has-upheld-a-puniti\">The Tennessee Court of Appeals has upheld a punitive damages award against general contractor The Weitz Company, finding that the subcontract\u2019s general waiver of special damages did not bar recovery for <a href=\"https:\/\/www.myconstructionexpert.com\/blog\/the-misrepresentation-defense-strikes-again\/\">intentional misrepresentation<\/a>. The case arose from construction of a multi-building retirement community in Shelby County, Tennessee. Weitz hired Commercial Painting Company to perform the drywall work. Disputes arose, litigation ensued, and the case tried to a jury in October 2018.<\/p>\n\n\n\n<p id=\"the-jury-awarded-commercial-painting-company-compe\">The jury awarded Commercial Painting Company compensatory damages of $1,272,952.46 and punitive damages of $3.9 million. The trial court upheld this judgment after noting the jury\u2019s findings that Weitz acted in bad faith that was \u201cintentionally, recklessly, maliciously, or fraudulently such that the conduct was egregious.\u201d The court found Weitz knew the project was eight months behind schedule but did not tell Commercial Painting about the delay, its plans to compress the construction schedule, or its plans to supplement Commercial Painting\u2019s drywall work. Weitz also misrepresented the length of an extension it obtained from the project owner while imposing an unrealistic schedule to earn an early completion bonus. Weitz also \u201cback charged\u201d Commercial Painting for work necessitated by incorrect framing done by another subcontractor, repairs to damage caused by other subcontractors, and charged Commercial Painting for a higher level of finish than the subcontract required.<\/p>\n\n\n\n<p id=\"on-appeal-weitz-argued-that-punitive-damages-were\">On appeal, Weitz argued that punitive damages were barred under the subcontracts\u2019 waiver of consequential and special damages. The Court of Appeals recognized a split of authority on whether contractual waivers bar fraud claims. Some jurisdictions recognize that \u201ca whisper of fraud can topple the pillars of even the most impregnable contract,\u201d whereas other jurisdictions give force to specific contractual clauses disclaiming reliance on misrepresentations. The Tennessee Court of Appeals did not have to choose either approach because the waiver at issue did not specifically address fraud or misrepresentation and appeared to address contractual rather than tort remedies. The court therefore affirmed the trial court\u2019s judgment on the punitive damages award. A copy of the court\u2019s opinion in <em>Commercial Painting Company, Inc. v. The Weitz Company, LLC, No. W2019-02089-COA-R3-CV (Tenn. Ct. App. Oct. 28, 2026)<\/em>, is available <a href=\"https:\/\/www.buildsmartbradley.com\/wp-content\/uploads\/sites\/34\/2026\/11\/Commercial-Painting-Company-Inc-v.-The-Weitz-Company-LLC-Et-Al.pdf\" target=\"_blank\" rel=\"noreferrer noopener nofollow\">here<\/a>.<\/p>\n\n\n\n<hr class=\"wp-block-separator has-alpha-channel-opacity\"\/>\n\n\n\n<p><strong>When one of your cases is in need of a construction expert, estimates, insurance appraisal or umpire services in defect or insurance disputes &#8211; please call Advise &amp; Consult, Inc. at 801.641.8304, or email <a href=\"mailto:experts@adviseandconsult.net\">experts@adviseandconsult.net<\/a>.<\/strong><\/p>\n\n\n\n<p>Republished with permission. The article, \u201cFraud Claims Not Barred by Contractual Waiver: Tennessee Court Affirms Punitive Damages Award Against General Contractor\u201d was originally published on BuildSmart by Bradley Arant Boult Cummings LLP. Copyright 2026.<\/p>\n","protected":false},"excerpt":{"rendered":"<p>James Daniel and John Mark Goodman | BuildSmart The Tennessee Court of Appeals has upheld a punitive damages award against general contractor The Weitz Company, finding that the subcontract\u2019s general waiver of special damages did not bar recovery for intentional misrepresentation. The case arose from construction of a multi-building retirement community in Shelby County, Tennessee.&hellip; <a class=\"more-link\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/\">Continue reading <span class=\"screen-reader-text\">Fraud Claims Not Barred by Contractual Waiver: Tennessee Court Affirms Punitive Damages Award Against General Contractor<\/span><\/a><\/p>\n","protected":false},"author":1,"featured_media":0,"comment_status":"open","ping_status":"open","sticky":false,"template":"","format":"standard","meta":{"jetpack_post_was_ever_published":false,"_jetpack_newsletter_access":"","_jetpack_dont_email_post_to_subs":false,"_jetpack_newsletter_tier_id":0,"_jetpack_memberships_contains_paywalled_content":false,"_jetpack_memberships_contains_paid_content":false,"footnotes":"","jetpack_publicize_message":"","jetpack_publicize_feature_enabled":true,"jetpack_social_post_already_shared":true,"jetpack_social_options":{"image_generator_settings":{"template":"highway","enabled":false},"version":2}},"categories":[9],"tags":[9895,224,10995,12385,12384,352],"class_list":["post-906331","post","type-post","status-publish","format-standard","hentry","category-construction-contracts","tag-advise-consult","tag-construction-contract","tag-fraud-claim","tag-general-waiver-of-special-damages","tag-intentional-misrespresentation","tag-tennessee","entry"],"jetpack_publicize_connections":[],"yoast_head":"<!-- This site is optimized with the Yoast SEO plugin v25.0 - https:\/\/yoast.com\/wordpress\/plugins\/seo\/ -->\n<title>Fraud Claims Not Barred by Contractual Waiver: Tennessee Court Affirms Punitive Damages Award Against General Contractor - Advise &amp; Consult, Inc.<\/title>\n<meta name=\"description\" content=\"subcontract\u2019s general waiver of special damages did not bar recovery for fraud claims in intentional misrepresentation\" \/>\n<meta name=\"robots\" content=\"index, follow, max-snippet:-1, max-image-preview:large, max-video-preview:-1\" \/>\n<link rel=\"canonical\" href=\"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/\" \/>\n<meta property=\"og:locale\" content=\"en_US\" \/>\n<meta property=\"og:type\" content=\"article\" \/>\n<meta property=\"og:title\" content=\"Fraud Claims Not Barred by Contractual Waiver: Tennessee Court Affirms Punitive Damages Award Against General Contractor - Advise &amp; Consult, Inc.\" \/>\n<meta property=\"og:description\" content=\"subcontract\u2019s general waiver of special damages did not bar recovery for fraud claims in intentional misrepresentation\" \/>\n<meta property=\"og:url\" content=\"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/\" \/>\n<meta property=\"og:site_name\" content=\"Advise &amp; Consult, Inc.\" \/>\n<meta property=\"article:publisher\" content=\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\" \/>\n<meta property=\"article:published_time\" content=\"2026-11-10T22:53:55+00:00\" \/>\n<meta property=\"article:modified_time\" content=\"2026-11-10T22:53:58+00:00\" \/>\n<meta name=\"author\" content=\"admin\" \/>\n<meta name=\"twitter:card\" content=\"summary_large_image\" \/>\n<meta name=\"twitter:creator\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:site\" content=\"@adviseconsult\" \/>\n<meta name=\"twitter:label1\" content=\"Written by\" \/>\n\t<meta name=\"twitter:data1\" content=\"admin\" \/>\n\t<meta name=\"twitter:label2\" content=\"Est. reading time\" \/>\n\t<meta name=\"twitter:data2\" content=\"2 minutes\" \/>\n<script type=\"application\/ld+json\" class=\"yoast-schema-graph\">{\"@context\":\"https:\/\/schema.org\",\"@graph\":[{\"@type\":\"Article\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/#article\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/\"},\"author\":{\"name\":\"admin\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\"},\"headline\":\"Fraud Claims Not Barred by Contractual Waiver: Tennessee Court Affirms Punitive Damages Award Against General Contractor\",\"datePublished\":\"2026-11-10T22:53:55+00:00\",\"dateModified\":\"2026-11-10T22:53:58+00:00\",\"mainEntityOfPage\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/\"},\"wordCount\":449,\"commentCount\":0,\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"keywords\":[\"Advise &amp; Consult\",\"Construction Contract\",\"Fraud Claim\",\"General Waiver of Special Damages\",\"Intentional Misrespresentation\",\"Tennessee\"],\"articleSection\":[\"Construction Contracts\"],\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"CommentAction\",\"name\":\"Comment\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/#respond\"]}]},{\"@type\":\"WebPage\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/\",\"name\":\"Fraud Claims Not Barred by Contractual Waiver: Tennessee Court Affirms Punitive Damages Award Against General Contractor - Advise &amp; Consult, Inc.\",\"isPartOf\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\"},\"datePublished\":\"2026-11-10T22:53:55+00:00\",\"dateModified\":\"2026-11-10T22:53:58+00:00\",\"description\":\"subcontract\u2019s general waiver of special damages did not bar recovery for fraud claims in intentional misrepresentation\",\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"ReadAction\",\"target\":[\"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/\"]}]},{\"@type\":\"WebSite\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#website\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"name\":\"Advise &amp; Consult, Inc.\",\"description\":\"Construction Expert Witnesses\",\"publisher\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\"},\"potentialAction\":[{\"@type\":\"SearchAction\",\"target\":{\"@type\":\"EntryPoint\",\"urlTemplate\":\"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}\"},\"query-input\":{\"@type\":\"PropertyValueSpecification\",\"valueRequired\":true,\"valueName\":\"search_term_string\"}}],\"inLanguage\":\"en-US\"},{\"@type\":\"Organization\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#organization\",\"name\":\"Advise & Consult\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/\",\"logo\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\",\"url\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"contentUrl\":\"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png\",\"width\":162,\"height\":75,\"caption\":\"Advise & Consult\"},\"image\":{\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/\"},\"sameAs\":[\"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/\",\"https:\/\/x.com\/adviseconsult\",\"https:\/\/www.linkedin.com\/company-beta\/204526\/\",\"https:\/\/www.youtube.com\/user\/MrConstructionExpert\"]},{\"@type\":\"Person\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7\",\"name\":\"admin\",\"image\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/\",\"url\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"contentUrl\":\"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg\",\"caption\":\"admin\"},\"sameAs\":[\"http:\/\/www.expertwitnessinconstruction.com\"]}]}<\/script>\n<!-- \/ Yoast SEO plugin. -->","yoast_head_json":{"title":"Fraud Claims Not Barred by Contractual Waiver: Tennessee Court Affirms Punitive Damages Award Against General Contractor - Advise &amp; Consult, Inc.","description":"subcontract\u2019s general waiver of special damages did not bar recovery for fraud claims in intentional misrepresentation","robots":{"index":"index","follow":"follow","max-snippet":"max-snippet:-1","max-image-preview":"max-image-preview:large","max-video-preview":"max-video-preview:-1"},"canonical":"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/","og_locale":"en_US","og_type":"article","og_title":"Fraud Claims Not Barred by Contractual Waiver: Tennessee Court Affirms Punitive Damages Award Against General Contractor - Advise &amp; Consult, Inc.","og_description":"subcontract\u2019s general waiver of special damages did not bar recovery for fraud claims in intentional misrepresentation","og_url":"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/","og_site_name":"Advise &amp; Consult, Inc.","article_publisher":"https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","article_published_time":"2026-11-10T22:53:55+00:00","article_modified_time":"2026-11-10T22:53:58+00:00","author":"admin","twitter_card":"summary_large_image","twitter_creator":"@adviseconsult","twitter_site":"@adviseconsult","twitter_misc":{"Written by":"admin","Est. reading time":"2 minutes"},"schema":{"@context":"https:\/\/schema.org","@graph":[{"@type":"Article","@id":"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/#article","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/"},"author":{"name":"admin","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7"},"headline":"Fraud Claims Not Barred by Contractual Waiver: Tennessee Court Affirms Punitive Damages Award Against General Contractor","datePublished":"2026-11-10T22:53:55+00:00","dateModified":"2026-11-10T22:53:58+00:00","mainEntityOfPage":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/"},"wordCount":449,"commentCount":0,"publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"keywords":["Advise &amp; Consult","Construction Contract","Fraud Claim","General Waiver of Special Damages","Intentional Misrespresentation","Tennessee"],"articleSection":["Construction Contracts"],"inLanguage":"en-US","potentialAction":[{"@type":"CommentAction","name":"Comment","target":["https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/#respond"]}]},{"@type":"WebPage","@id":"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/","name":"Fraud Claims Not Barred by Contractual Waiver: Tennessee Court Affirms Punitive Damages Award Against General Contractor - Advise &amp; Consult, Inc.","isPartOf":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website"},"datePublished":"2026-11-10T22:53:55+00:00","dateModified":"2026-11-10T22:53:58+00:00","description":"subcontract\u2019s general waiver of special damages did not bar recovery for fraud claims in intentional misrepresentation","inLanguage":"en-US","potentialAction":[{"@type":"ReadAction","target":["https:\/\/www.myconstructionexpert.com\/blog\/fraud-claims-not-barred-by-contractual-waiver\/"]}]},{"@type":"WebSite","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#website","url":"https:\/\/www.myconstructionexpert.com\/blog\/","name":"Advise &amp; Consult, Inc.","description":"Construction Expert Witnesses","publisher":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization"},"potentialAction":[{"@type":"SearchAction","target":{"@type":"EntryPoint","urlTemplate":"https:\/\/www.myconstructionexpert.com\/blog\/?s={search_term_string}"},"query-input":{"@type":"PropertyValueSpecification","valueRequired":true,"valueName":"search_term_string"}}],"inLanguage":"en-US"},{"@type":"Organization","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#organization","name":"Advise & Consult","url":"https:\/\/www.myconstructionexpert.com\/blog\/","logo":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/","url":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","contentUrl":"https:\/\/www.myconstructionexpert.com\/blog\/wp-content\/uploads\/2015\/11\/AC-Red-Logo.png","width":162,"height":75,"caption":"Advise & Consult"},"image":{"@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/logo\/image\/"},"sameAs":["https:\/\/www.facebook.com\/Advise-Consult-Inc-126949043996790\/","https:\/\/x.com\/adviseconsult","https:\/\/www.linkedin.com\/company-beta\/204526\/","https:\/\/www.youtube.com\/user\/MrConstructionExpert"]},{"@type":"Person","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/0a11abe008083d5fb19c2b0feefe7bd7","name":"admin","image":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.myconstructionexpert.com\/blog\/#\/schema\/person\/image\/","url":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","contentUrl":"https:\/\/secure.gravatar.com\/avatar\/b01e71b7acadd7657af782b7ad1a30cc?s=96&d=mm&r=pg","caption":"admin"},"sameAs":["http:\/\/www.expertwitnessinconstruction.com"]}]}},"jetpack_featured_media_url":"","jetpack_sharing_enabled":true,"jetpack_shortlink":"https:\/\/wp.me\/p2ztG6-3NMf","jetpack_likes_enabled":true,"_links":{"self":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/906331","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/users\/1"}],"replies":[{"embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/comments?post=906331"}],"version-history":[{"count":1,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/906331\/revisions"}],"predecessor-version":[{"id":906332,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/posts\/906331\/revisions\/906332"}],"wp:attachment":[{"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/media?parent=906331"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/categories?post=906331"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.myconstructionexpert.com\/blog\/wp-json\/wp\/v2\/tags?post=906331"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}